Arizona Acuerdo General de Construcción entre el Propietario y el Contratista - General Construction Agreement between Property Owner and Contractor

• Category: Construcción - Generales
• State: Multi-State
• Control #: US-13248BG
• Format: Word

Description

A Construction Agreement is a mutual or legally binding agreement between two parties based on policies and conditions recorded in document form. The two parties involved are one or more property owners and one or more contractors Arizona General Construction Agreement is a legally binding contract entered into between a property owner and a contractor for the purpose of undertaking construction projects in the state of Arizona. This agreement outlines the terms and conditions under which the contractor is engaged to provide construction services to the property owner. The content of the agreement typically includes: 1. Parties to the Agreement: — Names and addresses of the property owner (referred to as the "Owner") and the contractor (referred to as the "Contractor"). — If applicable, the name of the project architect or engineer. 2. Project Description: — A detailed description of the construction project to be undertaken. — Architectural plans, engineering diagrams, and project specifications may be attached as exhibits. 3. Scope of Work: — A comprehensive outline of the specific tasks and services to be performed by the Contractor. — This section may include demolition, construction, installation, electrical, plumbing, finishing works, etc. 4. Timeline: — The project start date, completion date, and any important milestones or deadlines. — Provision for extensions of time due to unforeseen circumstances or delays beyond the control of the Contractor. 5. Construction Budget and Payment Terms: — The agreed-upon contract price for the construction project and payment schedule. — Provisions for invoicing, progress payments, and retention sums. — Any penalties or incentives for early completion or delays. 6. Permits and Insurances: — The responsibility for obtaining necessary permits and licenses required for the project. — Insurance requirements and indemnification provisions to protect both parties against liabilities. 7. Change Orders: — Provisions for addressing changes or additions to the original scope of work. — Procedures for requesting, approving, and documenting change orders and their impact on the project timeline and budget. 8. Termination or Suspension: — Conditions under which either party may terminate or suspend the agreement. — Rights and obligations of both parties upon termination. 9. Dispute Resolution: — Mechanisms for resolving disputes, such as mediation, arbitration, or litigation. — The governing law and jurisdiction in the event of legal action. Different types of Arizona General Construction Agreements may include variations based on the nature of the construction project or the type of property involved. Examples include residential construction agreements, commercial construction agreements, and government construction agreements. However, the core elements described above generally remain consistent across these different types of agreements.

Arizona General Construction Agreement is a legally binding contract entered into between a property owner and a contractor for the purpose of undertaking construction projects in the state of Arizona. This agreement outlines the terms and conditions under which the contractor is engaged to provide construction services to the property owner. The content of the agreement typically includes: 1. Parties to the Agreement: — Names and addresses of the property owner (referred to as the "Owner") and the contractor (referred to as the "Contractor"). — If applicable, the name of the project architect or engineer. 2. Project Description: — A detailed description of the construction project to be undertaken. — Architectural plans, engineering diagrams, and project specifications may be attached as exhibits. 3. Scope of Work: — A comprehensive outline of the specific tasks and services to be performed by the Contractor. — This section may include demolition, construction, installation, electrical, plumbing, finishing works, etc. 4. Timeline: — The project start date, completion date, and any important milestones or deadlines. — Provision for extensions of time due to unforeseen circumstances or delays beyond the control of the Contractor. 5. Construction Budget and Payment Terms: — The agreed-upon contract price for the construction project and payment schedule. — Provisions for invoicing, progress payments, and retention sums. — Any penalties or incentives for early completion or delays. 6. Permits and Insurances: — The responsibility for obtaining necessary permits and licenses required for the project. — Insurance requirements and indemnification provisions to protect both parties against liabilities. 7. Change Orders: — Provisions for addressing changes or additions to the original scope of work. — Procedures for requesting, approving, and documenting change orders and their impact on the project timeline and budget. 8. Termination or Suspension: — Conditions under which either party may terminate or suspend the agreement. — Rights and obligations of both parties upon termination. 9. Dispute Resolution: — Mechanisms for resolving disputes, such as mediation, arbitration, or litigation. — The governing law and jurisdiction in the event of legal action. Different types of Arizona General Construction Agreements may include variations based on the nature of the construction project or the type of property involved. Examples include residential construction agreements, commercial construction agreements, and government construction agreements. However, the core elements described above generally remain consistent across these different types of agreements.

Para su conveniencia, debajo del texto en español le brindamos la versión completa de este formulario en inglés. For your convenience, the complete English version of this form is attached below the Spanish version.