District of Columbia Acuerdo Integral de Proyecto entre Propietario y Arquitecto - Comprehensive Agreement for Project between Owner and Architect

• Category: Empleo - Contratistas independientes - Profesional
• State: Multi-State
• Control #: US-0138BG
• Format: Word

Description

An architect contract is an agreement whereby an architect agrees to provide architectural services for a Company. Under this agreement, the architect is an architect with respect to the company, and not an employee of the company. Through this agreement the architect prepares conceptual drawings and specifications and furnishes other services in connection with the planning and design of the Project and the company in return for such services provides remuneration for such work and for the furnishing of additional architectural services in connection with the Project. In many respects, the architect Contract is simply a short-form version of a consulting agreement. The District of Columbia Comprehensive Agreement for Project between Owner and Architect is a legal document that establishes the terms and conditions for a construction project in the District of Columbia. It is a mutually agreed-upon agreement between the owner of the project and the architect responsible for its design and coordination. This agreement provides a framework for the parties involved to clearly define their rights, responsibilities, and expectations during the project's duration. Key elements covered within the District of Columbia Comprehensive Agreement include project scope, design services, compensation, schedule, construction administration, dispute resolution, and project closeout. Each of these aspects plays a crucial role in ensuring a successful collaboration between the owner and architect. The project scope section outlines the objectives, deliverables, and constraints of the construction project. It discusses factors such as the size, purpose, and design intent while also incorporating sustainable design practices, building codes, and accessibility requirements. Effective communication and documentation play a crucial role in establishing a comprehensive project scope. Design services encompass the architectural professional services, which include schematic design, design development, construction documentation, and construction administration. These stages define the architect's responsibilities in creating the project design, collaborating with engineering consultants, obtaining necessary permits and approvals, coordinating with contractors, and responding to construction-phase issues. The compensation section of the agreement precisely delineates how the architect will be remunerated for their services. It includes payment terms, methods, and schedules, which may be based on a fixed fee, percentage of construction costs, or hourly rates. Additionally, it may cover reimbursable expenses such as travel costs, printing expenses, and consultant fees. The schedule outlines the project timeline, including key milestones, construction commencement, and completion dates. It aims to ensure that both parties are aligned with the project's timeline and expectations. Construction administration refers to the architect's role in overseeing the project during construction. This may include conducting site visits, reviewing shop drawings and submittals, attending project meetings, addressing contractor queries, reviewing change orders, and ensuring adherence to plans and specifications. Dispute resolution procedures are also addressed within the agreement to provide a mechanism for resolving conflicts or disagreements that may arise during the project. It may include mediation, arbitration, or other alternative dispute resolution methods that enable the parties to find a mutually satisfactory resolution. Finally, the project closeout section outlines the responsibilities and obligations of the architect upon project completion. This may include providing as-built drawings, warranties, operation and maintenance manuals, and any other relevant project documentation. Although there might not be different types of District of Columbia Comprehensive Agreements specifically tailored for projects between owners and architects, variations can exist based on project type, scale, and complexity. For instance, a single-family residential project may have a different set of agreements compared to a large-scale commercial or institutional project. In such cases, the agreement may be modified to meet the specific requirements and intricacies associated with each project type, while still adhering to the overall guidelines and principles outlined in the comprehensive agreement.

The District of Columbia Comprehensive Agreement for Project between Owner and Architect is a legal document that establishes the terms and conditions for a construction project in the District of Columbia. It is a mutually agreed-upon agreement between the owner of the project and the architect responsible for its design and coordination. This agreement provides a framework for the parties involved to clearly define their rights, responsibilities, and expectations during the project's duration. Key elements covered within the District of Columbia Comprehensive Agreement include project scope, design services, compensation, schedule, construction administration, dispute resolution, and project closeout. Each of these aspects plays a crucial role in ensuring a successful collaboration between the owner and architect. The project scope section outlines the objectives, deliverables, and constraints of the construction project. It discusses factors such as the size, purpose, and design intent while also incorporating sustainable design practices, building codes, and accessibility requirements. Effective communication and documentation play a crucial role in establishing a comprehensive project scope. Design services encompass the architectural professional services, which include schematic design, design development, construction documentation, and construction administration. These stages define the architect's responsibilities in creating the project design, collaborating with engineering consultants, obtaining necessary permits and approvals, coordinating with contractors, and responding to construction-phase issues. The compensation section of the agreement precisely delineates how the architect will be remunerated for their services. It includes payment terms, methods, and schedules, which may be based on a fixed fee, percentage of construction costs, or hourly rates. Additionally, it may cover reimbursable expenses such as travel costs, printing expenses, and consultant fees. The schedule outlines the project timeline, including key milestones, construction commencement, and completion dates. It aims to ensure that both parties are aligned with the project's timeline and expectations. Construction administration refers to the architect's role in overseeing the project during construction. This may include conducting site visits, reviewing shop drawings and submittals, attending project meetings, addressing contractor queries, reviewing change orders, and ensuring adherence to plans and specifications. Dispute resolution procedures are also addressed within the agreement to provide a mechanism for resolving conflicts or disagreements that may arise during the project. It may include mediation, arbitration, or other alternative dispute resolution methods that enable the parties to find a mutually satisfactory resolution. Finally, the project closeout section outlines the responsibilities and obligations of the architect upon project completion. This may include providing as-built drawings, warranties, operation and maintenance manuals, and any other relevant project documentation. Although there might not be different types of District of Columbia Comprehensive Agreements specifically tailored for projects between owners and architects, variations can exist based on project type, scale, and complexity. For instance, a single-family residential project may have a different set of agreements compared to a large-scale commercial or institutional project. In such cases, the agreement may be modified to meet the specific requirements and intricacies associated with each project type, while still adhering to the overall guidelines and principles outlined in the comprehensive agreement.

Para su conveniencia, debajo del texto en español le brindamos la versión completa de este formulario en inglés. For your convenience, the complete English version of this form is attached below the Spanish version.