Florida Acuerdo General de Construcción entre el Propietario y el Contratista - General Construction Agreement between Property Owner and Contractor

• Category: Construcción - Generales
• State: Multi-State
• Control #: US-13248BG
• Format: Word

Description

A Construction Agreement is a mutual or legally binding agreement between two parties based on policies and conditions recorded in document form. The two parties involved are one or more property owners and one or more contractors Florida General Construction Agreement between Property Owner and Contractor is a legally binding document that outlines the terms and conditions of a construction project in the state of Florida. This agreement sets out the rights, responsibilities, and obligations of both the property owner and the contractor involved in the construction project. The agreement typically includes the following key elements: 1. Project Description: A detailed description of the construction project, including the scope of work to be done, specifications, and any special conditions or requirements. 2. Parties Involved: The agreement identifies the property owner (referred to as the "Owner") and the contractor (referred to as the "Contractor") responsible for carrying out the construction work. 3. Payment Terms: The agreement specifies the payment terms, including the total contract price, payment schedule, and any provisions for change orders or additional costs. 4. Duration of the Project: The agreement outlines the estimated start and completion dates for the construction project. It may also include provisions for delays or extensions of the project timeline. 5. Insurance and Liability: The agreement details the insurance requirements for both the property owner and the contractor, including general liability insurance, worker's compensation coverage, and any other necessary policies to protect all parties involved. 6. Permits and Approvals: The agreement states that the contractor is responsible for obtaining any necessary permits, licenses, or approvals required by local, state, or federal authorities to ensure compliance with building codes and regulations. 7. Quality of Work: The agreement sets forth the standards and expectations for the quality of work to be performed, including adherence to industry standards and compliance with applicable laws and regulations. 8. Change Orders: The agreement includes provisions for handling change orders or modifications to the original scope of work, including the process for requesting and approving changes, as well as any impact on the project timeline and budget. 9. Termination and Dispute Resolution: The agreement specifies the conditions under which either party can terminate the agreement and outlines the process for resolving disputes, including mediation, arbitration, or litigation. Different types of Florida General Construction Agreements between Property Owner and Contractor may include variations such as: 1. Lump Sum Agreement: This type of agreement specifies a fixed total contract price for the entire construction project, regardless of any changes or modifications to the scope of work. 2. Cost Plus Agreement: In this type of agreement, the property owner agrees to reimburse the contractor for the actual costs of labor, materials, and other expenses incurred during the construction project, along with an agreed-upon fee or percentage for overhead and profit. 3. Unit Price Agreement: This agreement establishes a price per unit of measurement (e.g., square foot, cubic yard) for various aspects of the construction project, allowing for flexibility in pricing based on the final quantity of work required. 4. Time and Material Agreement: This type of agreement is often used for smaller projects or repairs where the contractor charges the property owner based on the actual hours worked and materials used, typically including a markup for profit and overhead. It is important for both the property owner and the contractor to carefully review and understand the terms and conditions outlined in the Florida General Construction Agreement before signing, ensuring that all parties' rights and expectations are adequately protected throughout the construction project.

Florida General Construction Agreement between Property Owner and Contractor is a legally binding document that outlines the terms and conditions of a construction project in the state of Florida. This agreement sets out the rights, responsibilities, and obligations of both the property owner and the contractor involved in the construction project. The agreement typically includes the following key elements: 1. Project Description: A detailed description of the construction project, including the scope of work to be done, specifications, and any special conditions or requirements. 2. Parties Involved: The agreement identifies the property owner (referred to as the "Owner") and the contractor (referred to as the "Contractor") responsible for carrying out the construction work. 3. Payment Terms: The agreement specifies the payment terms, including the total contract price, payment schedule, and any provisions for change orders or additional costs. 4. Duration of the Project: The agreement outlines the estimated start and completion dates for the construction project. It may also include provisions for delays or extensions of the project timeline. 5. Insurance and Liability: The agreement details the insurance requirements for both the property owner and the contractor, including general liability insurance, worker's compensation coverage, and any other necessary policies to protect all parties involved. 6. Permits and Approvals: The agreement states that the contractor is responsible for obtaining any necessary permits, licenses, or approvals required by local, state, or federal authorities to ensure compliance with building codes and regulations. 7. Quality of Work: The agreement sets forth the standards and expectations for the quality of work to be performed, including adherence to industry standards and compliance with applicable laws and regulations. 8. Change Orders: The agreement includes provisions for handling change orders or modifications to the original scope of work, including the process for requesting and approving changes, as well as any impact on the project timeline and budget. 9. Termination and Dispute Resolution: The agreement specifies the conditions under which either party can terminate the agreement and outlines the process for resolving disputes, including mediation, arbitration, or litigation. Different types of Florida General Construction Agreements between Property Owner and Contractor may include variations such as: 1. Lump Sum Agreement: This type of agreement specifies a fixed total contract price for the entire construction project, regardless of any changes or modifications to the scope of work. 2. Cost Plus Agreement: In this type of agreement, the property owner agrees to reimburse the contractor for the actual costs of labor, materials, and other expenses incurred during the construction project, along with an agreed-upon fee or percentage for overhead and profit. 3. Unit Price Agreement: This agreement establishes a price per unit of measurement (e.g., square foot, cubic yard) for various aspects of the construction project, allowing for flexibility in pricing based on the final quantity of work required. 4. Time and Material Agreement: This type of agreement is often used for smaller projects or repairs where the contractor charges the property owner based on the actual hours worked and materials used, typically including a markup for profit and overhead. It is important for both the property owner and the contractor to carefully review and understand the terms and conditions outlined in the Florida General Construction Agreement before signing, ensuring that all parties' rights and expectations are adequately protected throughout the construction project.

Para su conveniencia, debajo del texto en español le brindamos la versión completa de este formulario en inglés. For your convenience, the complete English version of this form is attached below the Spanish version.