Massachusetts Contrato para la construcción de un edificio con el contratista para suministrar todos los materiales y realizar todo el trabajo según lo requieran los documentos contractuales enumerados - Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents

• Category: Contratistas de construcción - Contratos
• State: Multi-State
• Control #: US-13202BG
• Format: Word

Description

This form is a contract for the construction of a building with Contractor agreeing to furnish all materials and to perform all work as required by contracts enumerated in the contract for construction. The Massachusetts Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legally binding agreement that outlines the responsibilities, obligations, and rights of both the contractor and the client in a construction project. This contract follows a specific set of guidelines laid out in the Massachusetts state laws and regulations. The purpose of this contract is to ensure that the construction project is carried out efficiently, within the specified timeframe, and in accordance with the agreed-upon plans and specifications. It provides a comprehensive framework for all parties involved, including the contractor, subcontractors, suppliers, and the client, to understand their roles and obligations throughout the construction process. The essential elements typically found in a Massachusetts Contract for Construction of Building include: 1. Identification: This section includes the names and contact information of all parties involved in the contract, such as the contractor, the client, and their respective representatives. It may also include details regarding the project site and relevant permits. 2. Scope of Work: This section outlines the specific tasks, deliverables, and requirements of the construction project. It includes a detailed description of the work to be performed, the materials to be used, and any special considerations or specifications. 3. Contract Documents: The contract references and incorporates the enumerated contract documents, which include architectural plans, engineering drawings, specifications, and any other relevant documents. These documents serve as the basis for the contractor's performance and the client's expectations. 4. Schedule and Milestones: The contract specifies the project's start and completion dates, as well as any intermediate milestones or deadlines. This section ensures that the construction project progresses in a timely manner and allows the client to monitor the contractor's performance. 5. Payment Terms: The contract includes provisions for the agreed-upon payment schedule, which may be based on specific project milestones or a percentage of completion. It details any retain age or deductions that may apply and outlines the process for issuing change orders or addressing disputes related to payments. 6. Insurance and Indemnification: This section outlines the types and amounts of insurance coverage required by the contractor, subcontractors, and suppliers. It also addresses the responsibilities of each party in indemnifying the others against any claims arising from the construction project. 7. Dispute Resolution: The contract provides a mechanism for resolving disputes or disagreements that may arise during the construction process. It may stipulate a process for negotiation, mediation, or arbitration, depending on the parties' preferences. Different types of Massachusetts Contracts for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents may exist based on the specific nature of the construction project or industry. Examples include residential construction contracts, commercial construction contracts, industrial construction contracts, and government-funded construction contracts. Each type may have unique provisions and requirements tailored to the specific project's needs and regulatory environment.

The Massachusetts Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legally binding agreement that outlines the responsibilities, obligations, and rights of both the contractor and the client in a construction project. This contract follows a specific set of guidelines laid out in the Massachusetts state laws and regulations. The purpose of this contract is to ensure that the construction project is carried out efficiently, within the specified timeframe, and in accordance with the agreed-upon plans and specifications. It provides a comprehensive framework for all parties involved, including the contractor, subcontractors, suppliers, and the client, to understand their roles and obligations throughout the construction process. The essential elements typically found in a Massachusetts Contract for Construction of Building include: 1. Identification: This section includes the names and contact information of all parties involved in the contract, such as the contractor, the client, and their respective representatives. It may also include details regarding the project site and relevant permits. 2. Scope of Work: This section outlines the specific tasks, deliverables, and requirements of the construction project. It includes a detailed description of the work to be performed, the materials to be used, and any special considerations or specifications. 3. Contract Documents: The contract references and incorporates the enumerated contract documents, which include architectural plans, engineering drawings, specifications, and any other relevant documents. These documents serve as the basis for the contractor's performance and the client's expectations. 4. Schedule and Milestones: The contract specifies the project's start and completion dates, as well as any intermediate milestones or deadlines. This section ensures that the construction project progresses in a timely manner and allows the client to monitor the contractor's performance. 5. Payment Terms: The contract includes provisions for the agreed-upon payment schedule, which may be based on specific project milestones or a percentage of completion. It details any retain age or deductions that may apply and outlines the process for issuing change orders or addressing disputes related to payments. 6. Insurance and Indemnification: This section outlines the types and amounts of insurance coverage required by the contractor, subcontractors, and suppliers. It also addresses the responsibilities of each party in indemnifying the others against any claims arising from the construction project. 7. Dispute Resolution: The contract provides a mechanism for resolving disputes or disagreements that may arise during the construction process. It may stipulate a process for negotiation, mediation, or arbitration, depending on the parties' preferences. Different types of Massachusetts Contracts for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents may exist based on the specific nature of the construction project or industry. Examples include residential construction contracts, commercial construction contracts, industrial construction contracts, and government-funded construction contracts. Each type may have unique provisions and requirements tailored to the specific project's needs and regulatory environment.

Para su conveniencia, debajo del texto en español le brindamos la versión completa de este formulario en inglés. For your convenience, the complete English version of this form is attached below the Spanish version.