New Hampshire Contrato para la construcción de un edificio con el contratista para suministrar todos los materiales y realizar todo el trabajo según lo requieran los documentos contractuales enumerados - Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents

• Category: Contratistas de construcción - Contratos
• State: Multi-State
• Control #: US-13202BG
• Format: Word

Description

This form is a contract for the construction of a building with Contractor agreeing to furnish all materials and to perform all work as required by contracts enumerated in the contract for construction. A New Hampshire Contract for Construction of a Building with a Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legally binding agreement between a property owner (referred to as the "Owner") and a contractor (referred to as the "Contractor"). This contract outlines the terms and conditions under which the construction project will proceed, including the responsibilities and obligations of both parties. The key elements of this contract include: 1. Parties Involved: The contract identifies the Owner and the Contractor, including their legal names and physical addresses. It is important to ensure that both parties have the legal capacity to enter into this agreement. 2. Scope of Work: The contract clearly defines the scope of work to be performed by the Contractor. It outlines the specific tasks and deliverables required for the successful completion of the construction project. This may include site preparation, construction, installation, and any other related activities. 3. Contract Documents: The contract references and incorporates the enumerated contract documents that govern the project. These may include architectural drawings, engineering plans, specifications, permits, and any other relevant documents. It is crucial to ensure that all parties have access to these documents and are aware of their binding nature. 4. Project Timeline: A New Hampshire Contract for Construction will include a detailed project schedule with specific milestones and completion dates. Parties may include provisions for extensions of time due to unforeseen circumstances such as weather delays or changes in scope. 5. Materials and Equipment: The contract clearly states that the Contractor is responsible for providing all necessary materials, equipment, and labor required for the construction project. It should specify any quality standards or requirements for the materials to be used. 6. Payment and Pricing: The contract details the payment terms, including the total contract price, payment schedule, and methods of payment. It may include provisions for change orders, retain age, and any applicable taxes or fees. 7. Insurance and Liability: The contract typically requires the Contractor to carry appropriate insurance coverage, such as general liability and workers' compensation insurance, to protect both parties from potential risks and liabilities during the construction process. It may also outline indemnification provisions. 8. Dispute Resolution and Termination: The contract may include clauses for dispute resolution, such as mediation or arbitration, in case disagreements arise between the Owner and Contractor. It should also specify the circumstances under which either party may terminate the agreement. Different types of New Hampshire Contracts for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents may vary based on the complexity, size, and nature of the project. However, the fundamental elements mentioned above remain integral to all types of construction contracts. Additional provisions, specific to the project type or unique requirements, may also be included to address specialized considerations.

A New Hampshire Contract for Construction of a Building with a Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legally binding agreement between a property owner (referred to as the "Owner") and a contractor (referred to as the "Contractor"). This contract outlines the terms and conditions under which the construction project will proceed, including the responsibilities and obligations of both parties. The key elements of this contract include: 1. Parties Involved: The contract identifies the Owner and the Contractor, including their legal names and physical addresses. It is important to ensure that both parties have the legal capacity to enter into this agreement. 2. Scope of Work: The contract clearly defines the scope of work to be performed by the Contractor. It outlines the specific tasks and deliverables required for the successful completion of the construction project. This may include site preparation, construction, installation, and any other related activities. 3. Contract Documents: The contract references and incorporates the enumerated contract documents that govern the project. These may include architectural drawings, engineering plans, specifications, permits, and any other relevant documents. It is crucial to ensure that all parties have access to these documents and are aware of their binding nature. 4. Project Timeline: A New Hampshire Contract for Construction will include a detailed project schedule with specific milestones and completion dates. Parties may include provisions for extensions of time due to unforeseen circumstances such as weather delays or changes in scope. 5. Materials and Equipment: The contract clearly states that the Contractor is responsible for providing all necessary materials, equipment, and labor required for the construction project. It should specify any quality standards or requirements for the materials to be used. 6. Payment and Pricing: The contract details the payment terms, including the total contract price, payment schedule, and methods of payment. It may include provisions for change orders, retain age, and any applicable taxes or fees. 7. Insurance and Liability: The contract typically requires the Contractor to carry appropriate insurance coverage, such as general liability and workers' compensation insurance, to protect both parties from potential risks and liabilities during the construction process. It may also outline indemnification provisions. 8. Dispute Resolution and Termination: The contract may include clauses for dispute resolution, such as mediation or arbitration, in case disagreements arise between the Owner and Contractor. It should also specify the circumstances under which either party may terminate the agreement. Different types of New Hampshire Contracts for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents may vary based on the complexity, size, and nature of the project. However, the fundamental elements mentioned above remain integral to all types of construction contracts. Additional provisions, specific to the project type or unique requirements, may also be included to address specialized considerations.

Para su conveniencia, debajo del texto en español le brindamos la versión completa de este formulario en inglés. For your convenience, the complete English version of this form is attached below the Spanish version.