This form is designed for use between Framing Contractors and Property Owners and may be executed with either a cost plus or fixed fee payment arrangement. This contract addresses such matters as change orders, work site information, warranty and insurance. This form was specifically drafted to comply with the laws of the State of California.
The San Jose California Framing Contract for Contractor is a legal agreement between a contractor and a client or property owner in the city of San Jose, California, that outlines the terms and conditions for a framing project. This contract aims to ensure that the framing work is completed successfully, in compliance with local building codes and regulations, while protecting the rights and interests of both parties involved. A San Jose California Framing Contract for Contractor typically includes several important sections: 1. Parties: This section identifies the contractor, also known as the framer, and the client or property owner. It includes their contact information and legal names. 2. Scope of Work: This section provides a detailed description of the framing project, outlining the specific tasks, materials, and techniques that will be used, such as wood or metal framing, sheathing, beams, trusses, or other structural components. 3. Project Timeline: This section specifies the expected start and completion dates of the framing work. It may also include milestones, progress reports, and any potential penalties for delays. 4. Payment Terms: This section outlines the financial aspects of the contract. It includes the total cost of the project, the payment schedule (e.g., lump sum, partial payments based on completion stages), and the acceptable forms of payment. 5. Permits and Insurance: This section emphasizes the contractor's responsibility to obtain the necessary permits and licenses required by San Jose authorities. It may also require the contractor to carry liability insurance coverage. 6. Change Orders: This section addresses any potential changes or modifications requested by the client during the course of the framing project. It details the procedure for submitting and approving change orders, as well as any associated cost adjustments. 7. Termination Clause: This section specifies the circumstances under which either party can terminate the contract, such as non-performance, breach of contract, or mutual agreement. It outlines the rights and obligations of both parties in case of termination. 8. Dispute Resolution: This section outlines the preferred method for resolving disputes between the contractor and the client, such as mediation, arbitration, or litigation. It may also include a jurisdiction clause, determining which court will have jurisdiction over any legal disputes. Different types of San Jose California Framing Contracts for Contractors may include variations in terms, conditions, and specifications based on the complexity of the framing project, architectural requirements, or the particular needs and preferences of the client. Some examples of these variations include residential framing contracts, commercial framing contracts, or contracts for specialized framing projects such as timber framing or heavy timber construction.The San Jose California Framing Contract for Contractor is a legal agreement between a contractor and a client or property owner in the city of San Jose, California, that outlines the terms and conditions for a framing project. This contract aims to ensure that the framing work is completed successfully, in compliance with local building codes and regulations, while protecting the rights and interests of both parties involved. A San Jose California Framing Contract for Contractor typically includes several important sections: 1. Parties: This section identifies the contractor, also known as the framer, and the client or property owner. It includes their contact information and legal names. 2. Scope of Work: This section provides a detailed description of the framing project, outlining the specific tasks, materials, and techniques that will be used, such as wood or metal framing, sheathing, beams, trusses, or other structural components. 3. Project Timeline: This section specifies the expected start and completion dates of the framing work. It may also include milestones, progress reports, and any potential penalties for delays. 4. Payment Terms: This section outlines the financial aspects of the contract. It includes the total cost of the project, the payment schedule (e.g., lump sum, partial payments based on completion stages), and the acceptable forms of payment. 5. Permits and Insurance: This section emphasizes the contractor's responsibility to obtain the necessary permits and licenses required by San Jose authorities. It may also require the contractor to carry liability insurance coverage. 6. Change Orders: This section addresses any potential changes or modifications requested by the client during the course of the framing project. It details the procedure for submitting and approving change orders, as well as any associated cost adjustments. 7. Termination Clause: This section specifies the circumstances under which either party can terminate the contract, such as non-performance, breach of contract, or mutual agreement. It outlines the rights and obligations of both parties in case of termination. 8. Dispute Resolution: This section outlines the preferred method for resolving disputes between the contractor and the client, such as mediation, arbitration, or litigation. It may also include a jurisdiction clause, determining which court will have jurisdiction over any legal disputes. Different types of San Jose California Framing Contracts for Contractors may include variations in terms, conditions, and specifications based on the complexity of the framing project, architectural requirements, or the particular needs and preferences of the client. Some examples of these variations include residential framing contracts, commercial framing contracts, or contracts for specialized framing projects such as timber framing or heavy timber construction.
Para su conveniencia, debajo del texto en español le brindamos la versión completa de este formulario en inglés. For your convenience, the complete English version of this form is attached below the Spanish version.
