This form is designed for use between Commercial Contractors and Property Owners and may be executed with either a cost plus or fixed fee payment arrangement. This contract addresses such matters as change orders, work site information, warranty and insurance. This form was specifically drafted to comply with the laws of the State of Texas.
The Harris Texas Commercial Contract for Contractor is a legally binding agreement established between a contractor and the client or project owner in Harris County, Texas. This contract governs the terms and conditions under which the contractor will provide construction, renovation, or repair services for a commercial project within the county. This comprehensive contract outlines the rights, duties, and obligations of both parties involved in the construction project. It serves as a roadmap for the successful completion of the commercial construction project, ensuring clarity and transparency throughout the process. The Harris Texas Commercial Contract for Contractor covers various aspects of the project, including: 1. Scope of Work: This section defines the specific services the contractor will be responsible for, such as constructing buildings, installing fixtures, performing electrical or plumbing work, and any other agreed-upon tasks. 2. Payment Terms: The contract describes the agreed-upon payment schedule, the total contract price, and any additional charges or reimbursements. It may include provisions for change orders, retain age, progress billing, and final payment. 3. Project Schedule: This section outlines the expected start and completion dates of the construction project. It also considers the timeline for phases, milestones, or project deliverable expectations. 4. Insurance and Liability: The contract typically requires the contractor to carry general liability insurance and workers' compensation coverage. It may also include details regarding indemnification and the responsibilities of each party in terms of liabilities, damages, and risks associated with the project. 5. Dispute Resolution: In case of any dispute or disagreement between the parties, the contract specifies the agreed-upon methods for resolving disputes, such as mediation, arbitration, or litigation. 6. Permits and Approvals: It is crucial to comply with local regulations and obtain the necessary permits for the project. This section outlines the responsibilities of both parties concerning obtaining permits, licenses, and other necessary approvals. 7. Termination Clause: This clause defines the circumstances under which the contract can be terminated by either party, providing the necessary notice period and potential remedies. Different types of Harris Texas Commercial Contracts for Contractors may exist depending on the nature of the project. Some examples include: 1. New Construction Contract: This type of contract is used when a contractor is engaged in the construction of a new commercial building or structure. 2. Renovation or Remodeling Contract: This contract is applicable when the contractor is hired to renovate or remodel an existing commercial property. 3. Maintenance and Repair Contract: This type of contract is used when a contractor is responsible for ongoing maintenance, repairs, or upgrades of a commercial property. In conclusion, the Harris Texas Commercial Contract for Contractor is a crucial legal document that establishes the rights and obligations of both the contractor and the client. It ensures a clear understanding of expectations, safeguards the interests of both parties, and paves the way for a successful commercial construction project in Harris County, Texas.The Harris Texas Commercial Contract for Contractor is a legally binding agreement established between a contractor and the client or project owner in Harris County, Texas. This contract governs the terms and conditions under which the contractor will provide construction, renovation, or repair services for a commercial project within the county. This comprehensive contract outlines the rights, duties, and obligations of both parties involved in the construction project. It serves as a roadmap for the successful completion of the commercial construction project, ensuring clarity and transparency throughout the process. The Harris Texas Commercial Contract for Contractor covers various aspects of the project, including: 1. Scope of Work: This section defines the specific services the contractor will be responsible for, such as constructing buildings, installing fixtures, performing electrical or plumbing work, and any other agreed-upon tasks. 2. Payment Terms: The contract describes the agreed-upon payment schedule, the total contract price, and any additional charges or reimbursements. It may include provisions for change orders, retain age, progress billing, and final payment. 3. Project Schedule: This section outlines the expected start and completion dates of the construction project. It also considers the timeline for phases, milestones, or project deliverable expectations. 4. Insurance and Liability: The contract typically requires the contractor to carry general liability insurance and workers' compensation coverage. It may also include details regarding indemnification and the responsibilities of each party in terms of liabilities, damages, and risks associated with the project. 5. Dispute Resolution: In case of any dispute or disagreement between the parties, the contract specifies the agreed-upon methods for resolving disputes, such as mediation, arbitration, or litigation. 6. Permits and Approvals: It is crucial to comply with local regulations and obtain the necessary permits for the project. This section outlines the responsibilities of both parties concerning obtaining permits, licenses, and other necessary approvals. 7. Termination Clause: This clause defines the circumstances under which the contract can be terminated by either party, providing the necessary notice period and potential remedies. Different types of Harris Texas Commercial Contracts for Contractors may exist depending on the nature of the project. Some examples include: 1. New Construction Contract: This type of contract is used when a contractor is engaged in the construction of a new commercial building or structure. 2. Renovation or Remodeling Contract: This contract is applicable when the contractor is hired to renovate or remodel an existing commercial property. 3. Maintenance and Repair Contract: This type of contract is used when a contractor is responsible for ongoing maintenance, repairs, or upgrades of a commercial property. In conclusion, the Harris Texas Commercial Contract for Contractor is a crucial legal document that establishes the rights and obligations of both the contractor and the client. It ensures a clear understanding of expectations, safeguards the interests of both parties, and paves the way for a successful commercial construction project in Harris County, Texas.
Para su conveniencia, debajo del texto en español le brindamos la versión completa de este formulario en inglés. For your convenience, the complete English version of this form is attached below the Spanish version.
