This form is designed for use between Framing Contractors and Property Owners and may be executed with either a cost plus or fixed fee payment arrangement. This contract addresses such matters as change orders, work site information, warranty and insurance. This form was specifically drafted to comply with the laws of the State of Texas.
Wichita Falls Texas Framing Contract for Contractor is a legally binding agreement that outlines the terms and conditions between a contractor and their client for framing services in Wichita Falls, Texas. This contract ensures a clear understanding and sets expectations for both parties involved in any framing construction project. The Wichita Falls Texas Framing Contract for Contractor typically includes the following relevant keywords: 1. Scope of Work: This section specifies the exact framing services to be provided by the contractor. It details the type of framing work to be done, such as wood framing, steel framing, or concrete framing, and outlines any specific requirements or materials needed. 2. Project Timeline: The contract includes a timeframe for project completion, detailing the start and end dates of the framing work. It may also outline milestone dates or specific deadlines for certain phases of the project. 3. Payment Terms: This section outlines the financial aspects of the contract, including the total cost of the framing project, payment schedule, and any additional fees or expenses. It may specify whether payment is to be made in installments or upon completion of the project. 4. Insurance and Liability: The contract may require the contractor to have valid insurance coverage, including general liability and worker's compensation insurance, to protect both parties from potential damages or accidents that may occur during the framing project. 5. Change Orders: In case there are any modifications or adjustments required during the construction process, the contract should outline the procedure for change orders. This section describes how changes in scope or additional work will be addressed, including associated costs and potential delays. 6. Termination Clause: This clause outlines the conditions under which either party can terminate the contract. It may include specific reasons for termination, such as breaches of contract or failure to perform, and any associated penalties or consequences. 7. Dispute Resolution: If any disputes arise during the project, this section outlines the preferred method of resolution, such as mediation or arbitration. It helps to ensure that any issues can be resolved promptly and amicably, without the need for costly and time-consuming litigation. Different types of Wichita Falls Texas Framing Contracts for Contractors may include variations in specific details or terms based on the nature of the framing project. For example, contracts may differ for residential framing, commercial framing, or industrial framing projects. Each contract will reflect the unique requirements, complexities, and legal considerations associated with these specific types of framing work.Wichita Falls Texas Framing Contract for Contractor is a legally binding agreement that outlines the terms and conditions between a contractor and their client for framing services in Wichita Falls, Texas. This contract ensures a clear understanding and sets expectations for both parties involved in any framing construction project. The Wichita Falls Texas Framing Contract for Contractor typically includes the following relevant keywords: 1. Scope of Work: This section specifies the exact framing services to be provided by the contractor. It details the type of framing work to be done, such as wood framing, steel framing, or concrete framing, and outlines any specific requirements or materials needed. 2. Project Timeline: The contract includes a timeframe for project completion, detailing the start and end dates of the framing work. It may also outline milestone dates or specific deadlines for certain phases of the project. 3. Payment Terms: This section outlines the financial aspects of the contract, including the total cost of the framing project, payment schedule, and any additional fees or expenses. It may specify whether payment is to be made in installments or upon completion of the project. 4. Insurance and Liability: The contract may require the contractor to have valid insurance coverage, including general liability and worker's compensation insurance, to protect both parties from potential damages or accidents that may occur during the framing project. 5. Change Orders: In case there are any modifications or adjustments required during the construction process, the contract should outline the procedure for change orders. This section describes how changes in scope or additional work will be addressed, including associated costs and potential delays. 6. Termination Clause: This clause outlines the conditions under which either party can terminate the contract. It may include specific reasons for termination, such as breaches of contract or failure to perform, and any associated penalties or consequences. 7. Dispute Resolution: If any disputes arise during the project, this section outlines the preferred method of resolution, such as mediation or arbitration. It helps to ensure that any issues can be resolved promptly and amicably, without the need for costly and time-consuming litigation. Different types of Wichita Falls Texas Framing Contracts for Contractors may include variations in specific details or terms based on the nature of the framing project. For example, contracts may differ for residential framing, commercial framing, or industrial framing projects. Each contract will reflect the unique requirements, complexities, and legal considerations associated with these specific types of framing work.
Para su conveniencia, debajo del texto en español le brindamos la versión completa de este formulario en inglés. For your convenience, the complete English version of this form is attached below the Spanish version.
