Suffolk New York Contrato para la construcción de un edificio con el contratista para suministrar todos los materiales y realizar todo el trabajo según lo requieran los documentos contractuales enumerados - Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents

• Category: Contratistas de construcción - Contratos
• State: Multi-State
• County: Suffolk
• Control #: US-13202BG
• Format: Word

Description

This form is a contract for the construction of a building with Contractor agreeing to furnish all materials and to perform all work as required by contracts enumerated in the contract for construction. A Suffolk New York Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legal agreement between a property owner and a contractor in Suffolk County, New York. This contract outlines the specific terms and conditions under which the contractor will provide construction services, including supplying all necessary materials and completing all required tasks as outlined in the contract documents. The purpose of this contract is to ensure that both parties are aware of their respective responsibilities and obligations throughout the construction process. The Suffolk New York Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents typically includes the following key components: 1. Parties involved: This section identifies the property owner, referred to as the "Owner," and the contractor, known as the "Contractor," along with their contact information. 2. Scope of work: This portion outlines the specific work that needs to be performed, including the construction tasks, materials required, and any special considerations or requirements. 3. Contract documents: This section includes a detailed list of the contract documents that will govern the construction project. These may include architectural plans, engineering drawings, specifications, and any other relevant documents. 4. Project timeline: The contract will specify the start and completion dates for the construction project. It may also outline any milestones or deadlines that need to be met during the construction process. 5. Payment terms: The contract will clearly define the financial aspects of the agreement. This includes the total contract price, any agreed-upon payment schedule, and the terms of payment, such as whether the payment will be made in installments or lump sum upon completion. 6. Change orders: This section addresses the process for managing any changes or modifications to the original scope of work. It outlines the procedure for requesting a change order, the associated costs, and any impact on the project timeline. 7. Insurance and liability: This part of the contract focuses on insurance requirements, indemnification clauses, and the allocation of responsibility for any damages, accidents, or injuries that may occur during the construction process. 8. Dispute resolution: The contract may include provisions for resolving disputes, such as mandatory mediation or arbitration, to avoid costly litigation. Different types of Suffolk New York Contracts for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents may include variations based on the scale and complexity of the construction project. These could include contracts for residential construction, commercial construction, government projects, renovations, or remodeling projects. Each type of contract will have specific clauses and requirements tailored to the particular needs of that project.

A Suffolk New York Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legal agreement between a property owner and a contractor in Suffolk County, New York. This contract outlines the specific terms and conditions under which the contractor will provide construction services, including supplying all necessary materials and completing all required tasks as outlined in the contract documents. The purpose of this contract is to ensure that both parties are aware of their respective responsibilities and obligations throughout the construction process. The Suffolk New York Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents typically includes the following key components: 1. Parties involved: This section identifies the property owner, referred to as the "Owner," and the contractor, known as the "Contractor," along with their contact information. 2. Scope of work: This portion outlines the specific work that needs to be performed, including the construction tasks, materials required, and any special considerations or requirements. 3. Contract documents: This section includes a detailed list of the contract documents that will govern the construction project. These may include architectural plans, engineering drawings, specifications, and any other relevant documents. 4. Project timeline: The contract will specify the start and completion dates for the construction project. It may also outline any milestones or deadlines that need to be met during the construction process. 5. Payment terms: The contract will clearly define the financial aspects of the agreement. This includes the total contract price, any agreed-upon payment schedule, and the terms of payment, such as whether the payment will be made in installments or lump sum upon completion. 6. Change orders: This section addresses the process for managing any changes or modifications to the original scope of work. It outlines the procedure for requesting a change order, the associated costs, and any impact on the project timeline. 7. Insurance and liability: This part of the contract focuses on insurance requirements, indemnification clauses, and the allocation of responsibility for any damages, accidents, or injuries that may occur during the construction process. 8. Dispute resolution: The contract may include provisions for resolving disputes, such as mandatory mediation or arbitration, to avoid costly litigation. Different types of Suffolk New York Contracts for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents may include variations based on the scale and complexity of the construction project. These could include contracts for residential construction, commercial construction, government projects, renovations, or remodeling projects. Each type of contract will have specific clauses and requirements tailored to the particular needs of that project.

Para su conveniencia, debajo del texto en español le brindamos la versión completa de este formulario en inglés. For your convenience, the complete English version of this form is attached below the Spanish version.