Harris Texas Contrato Básico de Construcción de un Edificio - Basic Contract for Construction of a Building

• Category: Contratistas de construcción - Contratos
• State: Multi-State
• County: Harris
• Control #: US-13353BG
• Format: Word

Description

This form is a sample of a basic contract for construction of a building between a contractor and the owner of a building. Harris Texas Basic Contract for Construction of a Building is a legally binding agreement that outlines the terms and conditions between the owner or developer of a construction project and the contractor. This contract serves to establish a clear understanding of the scope of work, responsibilities, and obligations of both parties involved in the construction process. The Harris Texas Basic Contract for Construction of a Building is specifically tailored to comply with local laws and regulations in Harris County, Texas. It embodies crucial elements necessary for the successful completion of a construction project while protecting the rights and interests of all parties involved. Some key components typically included in the Harris Texas Basic Contract for Construction of a Building are: 1. Identification of Parties: The contract clearly identifies the owner or developer and the contractor involved in the project, along with their relevant contact details. 2. Scope of Work: This section comprehensively defines the work to be performed, including detailed plans, specifications, materials, and any specific requirements or standards to be met. 3. Contract Price: The agreed-upon contract price is specified, including any allowances, deductions, or change order procedures. Payment terms and schedule, as well as any retain age provisions, are also outlined. 4. Performance Schedule: A detailed timeline for the construction project is established, with specific milestones, starting and completion dates, and any associated penalties or incentives for completion. 5. Permits and Approvals: The contract may address the responsibility for obtaining necessary permits, licenses, and approvals, and the party responsible for associated fees and documentation. 6. Insurance and Indemnification: Provisions regarding insurance coverage and liability are typically included, with requirements for general liability, workers' compensation, and any additional insurance policies necessary for the project. 7. Changes and Modifications: Procedures for handling changes, modifications, and any potential disputes or claims are specified, along with provisions for extra work, cost adjustments, and approval processes. 8. Termination and Default: This section outlines the circumstances under which either party can terminate the contract, including provisions for default, non-performance, or breach of contract. 9. Dispute Resolution: The contract may include methods for resolving disputes, such as mediation or arbitration, and the applicable laws or jurisdiction for settling any legal matters. It is important to note that there might be variations or specific types of Harris Texas Basic Contracts for Construction of a Building depending on factors such as project size, complexity, or specific industry requirements. These variations may include more specialized contracts, such as GMP (Guaranteed Maximum Price) contracts, Design-Build contracts, or Construction Manager at Risk contracts. When entering into a Harris Texas Basic Contract for Construction of a Building, it is crucial for all parties involved to carefully review and understand the terms, seek legal advice if necessary, and ensure that the contract adequately reflects the scope, expectations, and obligations for a successful construction project.

Harris Texas Basic Contract for Construction of a Building is a legally binding agreement that outlines the terms and conditions between the owner or developer of a construction project and the contractor. This contract serves to establish a clear understanding of the scope of work, responsibilities, and obligations of both parties involved in the construction process. The Harris Texas Basic Contract for Construction of a Building is specifically tailored to comply with local laws and regulations in Harris County, Texas. It embodies crucial elements necessary for the successful completion of a construction project while protecting the rights and interests of all parties involved. Some key components typically included in the Harris Texas Basic Contract for Construction of a Building are: 1. Identification of Parties: The contract clearly identifies the owner or developer and the contractor involved in the project, along with their relevant contact details. 2. Scope of Work: This section comprehensively defines the work to be performed, including detailed plans, specifications, materials, and any specific requirements or standards to be met. 3. Contract Price: The agreed-upon contract price is specified, including any allowances, deductions, or change order procedures. Payment terms and schedule, as well as any retain age provisions, are also outlined. 4. Performance Schedule: A detailed timeline for the construction project is established, with specific milestones, starting and completion dates, and any associated penalties or incentives for completion. 5. Permits and Approvals: The contract may address the responsibility for obtaining necessary permits, licenses, and approvals, and the party responsible for associated fees and documentation. 6. Insurance and Indemnification: Provisions regarding insurance coverage and liability are typically included, with requirements for general liability, workers' compensation, and any additional insurance policies necessary for the project. 7. Changes and Modifications: Procedures for handling changes, modifications, and any potential disputes or claims are specified, along with provisions for extra work, cost adjustments, and approval processes. 8. Termination and Default: This section outlines the circumstances under which either party can terminate the contract, including provisions for default, non-performance, or breach of contract. 9. Dispute Resolution: The contract may include methods for resolving disputes, such as mediation or arbitration, and the applicable laws or jurisdiction for settling any legal matters. It is important to note that there might be variations or specific types of Harris Texas Basic Contracts for Construction of a Building depending on factors such as project size, complexity, or specific industry requirements. These variations may include more specialized contracts, such as GMP (Guaranteed Maximum Price) contracts, Design-Build contracts, or Construction Manager at Risk contracts. When entering into a Harris Texas Basic Contract for Construction of a Building, it is crucial for all parties involved to carefully review and understand the terms, seek legal advice if necessary, and ensure that the contract adequately reflects the scope, expectations, and obligations for a successful construction project.

Para su conveniencia, debajo del texto en español le brindamos la versión completa de este formulario en inglés. For your convenience, the complete English version of this form is attached below the Spanish version.