Unconditional Waiver and Release upon Final Payment: This form releases the owner of a parcel of land, of any liens he/ she may have had placed on the land by a materialman. The release is issued as a consequence of the payment in full, which was agreed upon, in either their written or oral contract. This form is available in either Word or Rich Text format.
We use cookies to improve security, personalize the user experience, enhance our marketing activities (including cooperating with our marketing partners) and for other business use.
Click "here" to read our Cookie Policy. By clicking "Accept" you agree to the use of cookies. Read less
Read more
- US Legal Forms
- Waiver and Release Forms
-
California Unconditional Waiver and Release Upon Final Payment
Unconditional Final Release California Form
State:
California
Control #:
CA-LIEN-6
Format:
Word;
Rich Text
Instant download
Description Ca Waiver Payment
Ca Waiver Form Document Related forms
View Landlord tenant damages without registration
View Landlord tenant damages without registration
View this form
View Landlord tenant damages without repairs
View Landlord tenant damages without repairs
View this form
View Landlord tenant enjoyment form
View Landlord tenant enjoyment form
View this form
View Landlord tenant enjoyment without
View Landlord tenant enjoyment without
View this form
View Landlord tenant eviction forms
View Landlord tenant eviction forms
View this form
How to fill out California Final Form Ca?
There's no more reason to spend hours browsing for legal documents to comply with your local state regulations. US Legal Forms has gathered all of them in one place and streamlined their accessibility. Our platform offers more than 85k templates for any business and personal legal cases grouped by state and area of use All forms are appropriately drafted and verified for validity, so you can rest assured in getting an up-to-date Unconditional Final Release California Form.
If you are familiar with our service and already have an account, you need to ensure your subscription is valid before getting any templates. Log in to your account, choose the document, and click Download. You can also get back to all saved paperwork any moment needed by opening the My Forms tab in your profile.
If you've never used our service before, the process will take a few more actions to complete. Here's how new users can find the Unconditional Final Release California Form in our library:
- Read the page content carefully to ensure it contains the sample you need.
- To do so, utilize the form description and preview options if any.
- Use the Seach field above to locate another sample if the current one didn't suit you.
- Click Buy Now next to the template title once you find the correct one.
- Pick the best suitable pricing plan and register for an account or log in.
- Pay for your subscription with a credit card or via PayPal to proceed.
- Pick the file format for your Unconditional Final Release California Form and download it to your device.
- Print your form to fill it out in writing or upload the sample if you prefer to do it in an online editor.
Preparing formal paperwork under federal and state laws is quick and simple with our library. Try US Legal Forms today to keep your documentation in order!
Ca Waiver Form Form Rating
4.7
Satisfied(343)
Ca Waiver Final Payment Sample Form popularity
Ca Waiver Final Payment Other Form Names
Ca Waiver Final
Ca Unconditional Waiver Release Pdf
Ca Unconditional Waiver Release Payment
Ca Unconditional Waiver Release Form
Ca Unconditional Waiver Release Final
Ca Unconditional Waiver Release California
Ca Unconditional Waiver Release
Ca Unconditional Waiver Payment Form FAQ
How to complete the Conditional Waiver and Release on Progress Payment formName of Claimant. The claimant is the party receiving the payment in other words, the one waiving their lien rights.Name of Customer.Job Location.Owner.Through Date.Maker of the Check.Amount of the Check.Check Payable To.More items...?
Lien waivers generally come in two forms: conditional and unconditional. In a nutshell, conditional lien waivers show how much money is owing through a particular date, and unconditional lien waivers show how much money has been paid for work through a particular date.
No, California lien waivers do not need to be notarized, even though it's common for businesses to ask that waivers be notarized.
An unconditional release means no restrictions are imposed on the release of the lien. This type of lien release is typically used in final project documents to verify the project completion, payment finalization, and your release of all future rights to file liens on the project.
How to fill out a Texas Conditional Waiver and Release on Final PaymentProject. Write the name of your project.Job No. Write your project number.Maker of check. Write the name of the person who issues the check.$ Write the amount found on the check.Payee(s) of check.Person with whom signer contracted.Owner.Location.More items...?
Unconditional Final Release California Form Related Searches
-
unconditional lien release pdf
-
california lien release form pdf
-
unconditional waiver and release on final payment pdf
-
cslb lien release
-
how to fill out a conditional waiver and release on progress payment
-
waiver and release of lien upon final payment
-
lien release california
-
release of lien form california
-
california lien release form pdf
-
unconditional waiver and release on final payment pdf
California Final Form Ca Interesting Questions
An Unconditional Final Release form in California is a legal document that signifies the completion of a construction project and releases the property owner from any future claims or liens by the contractor.
You should use an Unconditional Final Release form in California when you have received full payment for your construction work and are ready to release the property owner from any further obligations or claims.
Yes, it is recommended to use an Unconditional Final Release form even if you have previously signed a Conditional Release form. The Unconditional Final Release form ensures that you are releasing all claims, liens, and obligations upon receiving full payment.
An Unconditional Final Release form typically requires the name and address of the property owner, contractor, and project details. It should also include the amount of final payment received and a clear statement releasing all claims and liens.
Yes, there are legal requirements for an Unconditional Final Release form in California. The form must be in writing, signed by the contractor or their authorized representative, and should be notarized for added validity and enforceability.
It is generally advised not to make any modifications to the standard Unconditional Final Release form. Using the form as provided ensures that you are complying with the legal requirements and protecting your rights.
If you don't use an Unconditional Final Release form, you may still be susceptible to future claims or liens by the contractor. This could potentially lead to legal disputes, delays in obtaining clear title, or difficulties in selling the property.
Yes, an Unconditional Final Release form can be used for various types of construction projects in California, including residential, commercial, and public works projects. It helps in providing clarity and protection for both parties involved.
While notarization is not mandatory for an Unconditional Final Release form in California, it is highly recommended. Notarization adds an extra layer of authenticity to the document and may help in its enforceability if any legal disputes arise.
You can obtain an Unconditional Final Release form in California from various online legal document providers or consult an attorney to ensure you have the correct and updated form for your specific needs.
More info
Amount set forth below. If you have not been paid, use a conditional release form.An "Unconditional Waiver and Release Upon Progress Payment" discharges all claimant rights through a specific date with no stipulations. A lien waiver is a document from a contractor, subcontractor, material supplier, equipment lessor or other party to the construction project regarding payment. Learn when unconditional lien waivers and releases for progress payments are required in California in this complete guide. California, for instance, mandates the required forms.
Ca Unconditional Waiver Final Statement Trusted and secure by over 3 million people of the world’s leading companies
California Release And Waiver Of Liens On Full Payment Unconditional
Law summary
Unconditional Waiver and Release Upon Final Payment
Contractors - Construction Liens - California
California Code CALIFORNIA CIVIL CODE Division 4. General Provisions Part 6. Works of Improvement Title 1. Works of Improvement Generally Chapter 1. General Provisions Article 1. Definitions PART 6. WORKS OF IMPROVEMENT TITLE 1. WORKS OF IMPROVEMENT GENERALLY CHAPTER 1. GENERAL PROVISIONS Article 1. Definitions 8000. Unless the provision or context otherwise requires, the definitions in this article govern the construction of this part. 8002. "Admitted surety insurer" has the meaning provided in Section 995.120 of the Code of Civil Procedure. 8004. "Claimant" means a person that has a right under this part to record a claim of lien, give a stop payment notice, or assert a claim against a payment bond, or do any combination of the foregoing. 8006. "Construction lender" means either of the following: (a) A mortgagee or beneficiary under a deed of trust lending funds with which the cost of all or part of a work of improvement is to be paid, or the assignee or successor in interest of the mortgagee or beneficiary. (b) An escrow holder or other person holding funds provided by an owner, lender, or another person as a fund for(from)with which the cost of all or part of a work of improvement is to be paid. 8008. "Contract" means an agreement that provides for all or part of a work of improvement. 8010. "Contract price" means the price agreed to in a direct contract for a work of improvement. 8012. "Contractor" includes a direct contractor, subcontractor, or both. This section does not apply to Sections 8018 and 8046. 8014. "Design professional" means a person licensed as an architect pursuant to Chapter 3 (commencing with Section 5500) of Division 3 of the Business and Professions Code, licensed as a landscape architect pursuant to Chapter 3.5 (commencing with Section 5615) of Division 3 of the Business and Professions Code, registered as a professional engineer pursuant to Chapter 7 (commencing with Section 6700) of Division 3 of the Business and Professions Code, or licensed as a land surveyor pursuant to Chapter 15 (commencing with Section 8700) of Division 3 of the Business and Professions Code. 8016. "Direct contract" means a contract between an owner and a direct contractor that provides for all or part of a work of improvement. 8018. "Direct contractor" means a contractor that has a direct contractual relationship with an owner. A reference in another statute to a "prime contractor" in connection with the provisions in this part means a "direct contractor." 8020. For the purposes of Title 3 (commencing with Section 9000), "funds" means warrant, check, money, or bonds (if bonds are to be issued in payment of the public works contract). 8022. "Labor, service, equipment, or material" includes, but is not limited to, labor, skills, services, material, supplies, equipment, appliances, power, and surveying, provided for a work of improvement. 8024. (a) "Laborer" means a person who, acting as an employee, performs labor upon, or bestows skill or other necessary services on, a work of improvement. (b) "Laborer" includes a person or entity to which a portion of a laborer's compensation for a work of improvement, including, but not limited to, employer payments described in Section 1773.1 of the Labor Code and implementing regulations, is paid by agreement with that laborer or the collective bargaining agent of that laborer. (c) A person or entity described in subdivision (b) that has standing under applicable law to maintain a direct legal action, in its own name or as an assignee, to collect any portion of compensation owed for a laborer for a work of improvement, shall have standing to enforce any rights or claims of the laborer under this part, to the extent of the compensation agreed to be paid to the person or entity for labor on that improvement. This subdivision is intended to give effect to the longstanding public policy of this state to protect the entire compensation of a laborer on a work of improvement, regardless of the form in which that compensation is to be paid. 8026. "Lien" means a lien under Title 2 (commencing with Section 8160) and includes a lien of a design professional under Section 8302, a lien for a work of improvement under Section 8400, and a lien for a site improvement under Section 8402. 8028. "Material supplier" means a person that provides material or supplies to be used or consumed in a work of improvement. 8030. (a) For the purposes of Title 2 (commencing with Section 8160), "payment bond" means a bond given under Section 8600. (b) For the purposes of Title 3 (commencing with Section 9000), "payment bond" means a bond required by Section 9550. 8032. "Person" means an individual, corporation, public entity, business trust, estate, trust, partnership, limited liability company, association, or other entity. 8034. (a) For the purposes of Title 2 (commencing with Section 8160), "preliminary notice" means the notice provided for in Chapter 2 (commencing with Section 8200) of Title 2. (b) For the purposes of Title 3 (commencing with Section 9000), "preliminary notice" means the notice provided for in Chapter 3 (commencing with Section 9300) of Title 3. 8036. "Public entity" means the state, Regents of the University of California, a county, city, district, public authority, public agency, and any other political subdivision or public corporation in the state. 8038. "Public works contract" has the meaning provided in Section 1101 of the Public Contract Code. 8040. "Site" means the real property on which a work of improvement is situated or planned. 8042. "Site improvement" means any of the following work on real property: (a) Demolition or removal of improvements, trees, or other vegetation. (b) Drilling test holes. (c) Grading, filling, or otherwise improving the real property or a street, highway, or sidewalk in front of or adjoining the real property. (d) Construction or installation of sewers or other public utilities. (e) Construction of areas, vaults, cellars, or rooms under sidewalks. (f) Any other work or improvements in preparation of the site for a work of improvement. 8044. (a) (1) For the purposes of Title 2 (commencing with Section 8160), "stop payment notice" means the notice given by a claimant under Chapter 5 (commencing with Section 8500) of Title 2. (2) A stop payment notice given under Title 2 (commencing with Section 8160) may be bonded or unbonded. A "bonded stop payment notice" is a notice given with a bond under Section 8532. An "unbonded stop payment notice" is a notice not given with a bond under Section 8532. (3) Except to the extent Title 2 (commencing with Section 8160) distinguishes between a bonded and an unbonded stop payment notice, a reference in that title to a stop payment notice includes both a bonded and an unbonded notice. (b) For the purposes of Title 3 (commencing with Section 9000), "stop payment notice" means the notice given by a claimant under Chapter 4 (commencing with Section 9350) of Title 3. (c) A reference in another statute to a "stop notice" in connection with the remedies provided in this part means a stop payment notice. 8046. "Subcontractor" means a contractor that does not have a direct contractual relationship with an owner. The term includes a contractor that has a contractual relationship with a direct contractor or with another subcontractor. 8048. "Work" means labor, service, equipment, or material provided to a work of improvement. 8050. (a) "Work of improvement" includes, but is not limited to: (1) Construction, alteration, repair, demolition, or removal, in whole or in part, of, or addition to, a building, wharf, bridge, ditch, flume, aqueduct, well, tunnel, fence, machinery, railroad, or road. (2) Seeding, sodding, or planting of real property for landscaping purposes. (3) Filling, leveling, or grading of real property. (b) Except as otherwise provided in this part, "work of improvement" means the entire structure or scheme of improvement as a whole, and includes site improvement. Article 2. Miscellaneous Provisions 8052. (a) This part is operative on July 1, 2012. (b) Notwithstanding subdivision (a), the effectiveness of a notice given or other action taken on a work of improvement before July 1, 2012, is governed by the applicable law in effect before July 1, 2012, and not by this part. (c) A provision of this part, insofar as it is substantially the same as a previously existing provision relating to the same subject matter, shall be construed as a restatement and continuation thereof and not as a new enactment. 8054. (a) This part does not apply to a transaction governed by the Oil and Gas Lien Act (Chapter 2.5 (commencing with Section 1203.50) of Title 4 of Part 3 of the Code of Civil Procedure). (b) This part does not apply to or change improvement security under the Subdivision Map Act (Division 2 (commencing with Section 66410) of Title 7 of the Government Code). (c) This part does not apply to a transaction governed by Sections 20457 to 20464, inclusive, of the Public Contract Code. 8056. Except as otherwise provided in this part, Part 2 (commencing with Section 307) of the Code of Civil Procedure provides the rules of practice in proceedings under this part. 8058. For purposes of this part, "day" means a calendar day. 8060. (a) If this part provides for filing a contract, plan, or other paper with the county recorder, the provision is satisfied by filing the paper in the office of the county recorder of the county in which the work of improvement or part of it is situated. (b) If this part provides for recording a notice, claim of lien, release of lien, payment bond, or other paper, the provision is satisfied by filing the paper for record in the office of the county recorder of the county in which the work of improvement or part of it is situated. (c) The county recorder shall number, index, and preserve a contract, plan, or other paper presented for filing under this part, and shall number, index, and transcribe into the official records, in the same manner as a conveyance of real property, a notice, claim of lien, payment bond, or other paper recorded under this part. (d) The county recorder shall charge and collect the fees provided in Article 5 (commencing with Section 27360) of Chapter 6 of Part 3 of Division 2 of Title 3 of the Government Code for performing duties under this section. 8062. No act of an owner in good faith and in compliance with a provision of this part shall be construed to prevent a direct contractor's performance of the contract, or exonerate a surety on a performance or payment bond. 8064. An owner may give a notice or execute or file a document under this part on behalf of a co-owner if the owner acts on the co-owner's behalf and includes in the notice or document the name and address of the co-owner on whose behalf the owner acts. 8066. An act that may be done by or to a person under this part may be done by or to the person's agent to the extent the act is within the scope of the agent's authority. CHAPTER 2. NOTICE 8100. Notice under this part shall be in writing. Writing includes printing and typewriting. 8102. (a) Notice under this part shall, in addition to any other information required by statute for that type of notice, include all of the following information to the extent known to the person giving the notice: (1) The name and address of the owner or reputed owner. (2) The name and address of the direct contractor. (3) The name and address of the construction lender, if any. (4) A description of the site sufficient for identification, including the street address of the site, if any. If a sufficient legal description of the site is given, the effectiveness of the notice is not affected by the fact that the street address is erroneous or is omitted. (5) The name, address, and relationship to the parties of the person giving the notice. (6) If the person giving the notice is a claimant: (A) A general statement of the work provided. (B) The name of the person to or for whom the work is provided. (C) A statement or estimate of the claimant's demand, if any, after deducting all just credits and offsets. (b) Notice is not invalid by reason of any variance from the requirements of this section if the notice is sufficient to substantially inform the person given notice of the information required by this section and other information required in the notice. 8104. (a) A direct contractor or subcontractor on a work of improvement governed by this part that employs a laborer and fails to pay the full compensation due the laborer, including any employer payments described in Section 1773.1 of the Labor Code and implementing regulations, shall not later than the date the compensation became delinquent, give the laborer, the laborer's bargaining representative, if any, the construction lender or reputed construction lender, if any, and the owner or reputed owner, notice that includes all of the following information, in addition to the information required by Section 8102: (1) The name and address of the laborer, and of any person or entity described in subdivision (b) of Section 8024 to which employer payments are due. (2) The total number of straight time and overtime hours worked by the laborer on each job. (3) The amount then past due and owing. (b) Failure to give the notice required by subdivision (a) constitutes grounds for disciplinary action under the Contractors' State License Law, Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code. 8106. Except as otherwise provided by statute, notice under this part shall be given by any of the following means: (a) Personal delivery. (b) Mail in the manner provided in Section 8110. (c) Leaving the notice and mailing a copy in the manner provided in Section 415.20 of the Code of Civil Procedure for service of summons and complaint in a civil action. 8108. Except as otherwise provided by this part, notice under this part shall be given to the person to be notified at the person's residence, the person's place of business, or at any of the following addresses: (a) If the person to be notified is an owner other than a public entity, the owner's address shown on the direct contract, the building permit, or a construction trust deed. (b) If the person to be notified is a public entity, the office of the public entity or another address specified by the public entity in the contract or elsewhere for service of notices, papers, and other documents. (c) If the person to be notified is a construction lender, the construction lender's address shown on the construction loan agreement or construction trust deed. (d) If the person to be notified is a direct contractor or a subcontractor, the contractor's address shown on the building permit, on the contractor's contract, or on the records of the Contractors' State License Board. (e) If the person to be notified is a claimant, the claimant's address shown on the claimant's contract, preliminary notice, claim of lien, stop payment notice, or claim against a payment bond, or on the records of the Contractors' State License Board. (f) If the person to be notified is a surety on a bond, the surety' s address shown on the bond for service of notices, papers, and other documents, or on the records of the Department of Insurance. 8110. Except as otherwise provided by this part, notice by mail under this part shall be given by registered or certified mail, express mail, or overnight delivery by an express service carrier. 8114. A notice required by this part to be posted shall be displayed in a conspicuous location at the site. 8116. Notice under this part is complete and deemed to have been given at the following times: (a) If given by personal delivery, when delivered. (b) If given by mail, when deposited in the mail or with an express service carrier in the manner provided in Section 1013 of the Code of Civil Procedure. (c) If given by leaving the notice and mailing a copy in the manner provided in Section 415.20 of the Code of Civil Procedure for service of summons in a civil action, five days after mailing. (d) If given by posting, when displayed. (e) If given by recording, when recorded in the office of the county recorder. 8118. (a) Proof that notice was given to a person in the manner required by this part shall be made by a proof of notice declaration that states all of the following: (1) The type or description of the notice given. (2) The date, place, and manner of notice, and facts showing that notice was given in the manner required by statute. (3) The name and address of the person to which notice was given, and, if appropriate, the title or capacity in which the person was given notice. (b) If the notice is given by mail, the declaration shall be accompanied by one of the following: (1) Documentation provided by the United States Postal Service showing that payment was made to mail the notice using registered or certified mail, or express mail. (2) Documentation provided by an express service carrier showing that payment was made to send the notice using an overnight delivery service. (3) A return receipt, delivery confirmation, signature confirmation, tracking record, or other proof of delivery or attempted delivery provided by the United States Postal Service, or a photocopy of the record of delivery and receipt maintained by the United States Postal Service, showing the date of delivery and to whom delivered, or in the event of nondelivery, by the returned envelope itself. (4) A tracking record or other documentation provided by an express service carrier showing delivery or attempted delivery of the notice. CHAPTER 3. WAIVER AND RELEASE 8120. The provisions of this chapter apply to a work of improvement governed by this part. 8122. An owner, direct contractor, or subcontractor may not, by contract or otherwise, waive, affect, or impair any other claimant's rights under this part, whether with or without notice, and any term of a contract that purports to do so is void and unenforceable unless and until the claimant executes and delivers a waiver and release under this article. 8124. A claimant's waiver and release does not release the owner, construction lender, or surety on a payment bond from a lien or claim unless both of the following conditions are satisfied: (a) The waiver and release is in substantially the form provided in this article and is signed by the claimant. (b) If the release is a conditional release, there is evidence of payment to the claimant. Evidence of payment may be either of the following: (1) The claimant's endorsement on a single or joint payee check that has been paid by the financial institution on which it was drawn. (2) Written acknowledgment of payment by the claimant. 8126. An oral or written statement purporting to waive, release, impair or otherwise adversely affect a lien or claim is void and unenforceable and does not create an estoppel or impairment of the lien or claim unless either of the following conditions is satisfied: (a) The statement is pursuant to a waiver and release under this article. (b) The claimant has actually received payment in full for the claim. 8128. (a) A claimant may reduce the amount of, or release in its entirety, a stop payment notice. The reduction or release shall be in writing and may be given in a form other than a waiver and release form provided in this article. (b) The writing shall identify whether it is a reduction of the amount of the stop payment notice, or a release of the notice in its entirety. If the writing is a reduction, it shall state the amount of the reduction, and the amount to remain withheld after the reduction. (c) A claimant's reduction or release of a stop payment notice has the following effect: (1) The reduction or release releases the claimant's right to enforce payment of the claim stated in the notice to the extent of the reduction or release. (2) The reduction or release releases the person given the notice from the obligation to withhold funds pursuant to the notice to the extent of the reduction or release. (3) The reduction or release does not preclude the claimant from giving a subsequent stop payment notice that is timely and proper. (4) The reduction or release does not release any right of the claimant other than the right to enforce payment of the claim stated in the stop payment notice to the extent of the reduction or release. 8130. This article does not affect the enforceability of either an accord and satisfaction concerning a good faith dispute or an agreement made in settlement of an action pending in court if the accord and satisfaction or agreement and settlement make specific reference to the lien or claim. 8132. If a claimant is required to execute a waiver and release in exchange for, or in order to induce payment of, a progress payment and the claimant is not, in fact, paid in exchange for the waiver and release or a single payee check or joint payee check is given in exchange for the waiver and release, the waiver and release shall be null, void, and unenforceable unless it is in substantially the following form: CONDITIONAL WAIVER AND RELEASE ON PROGRESS PAYMENT NOTICE: THIS DOCUMENT WAIVES THE CLAIMANT'S LIEN, STOP PAYMENT NOTICE, AND PAYMENT BOND RIGHTS EFFECTIVE ON RECEIPT OF PAYMENT. A PERSON SHOULD NOT RELY ON THIS DOCUMENT UNLESS SATISFIED THAT THE CLAIMANT HAS RECEIVED PAYMENT. Identifying Information Name of Claimant:_______________________________ Name of Customer:_______________________________ Job Location:___________________________________ Owner:__________________________________________ Through Date:___________________________________ Conditional Waiver and Release This document waives and releases lien, stop payment notice, and payment bond rights the claimant has for labor and service provided, and equipment and material delivered, to the customer on this job through the Through Date of this document. Rights based upon labor or service provided, or equipment or material delivered, pursuant to a written change order that has been fully executed by the parties prior to the date that this document is signed by the claimant, are waived and released by this document, unless listed as an Exception below. This document is effective only on the claimant's receipt of payment from the financial institution on which the following check is drawn: Maker of Check:_________________________________ Amount of Check: $______________________________ Check Payable to:_______________________________ Exceptions This document does not affect any of the following: (1) Retentions. (2) Extras for which the claimant has not received payment. (3) The following progress payments for which the claimant has previously given a conditional waiver and release but has not received payment: Date(s) of waiver and release:__________________ Amount(s) of unpaid progress payment(s): $______ (4) Contract rights, including (A) a right based on rescission, abandonment, or breach of contract, and (B) the right to recover compensation for work not compensated by the payment. Signature Claimant's Signature:___________________________ Claimant's Title:_______________________________ Date of Signature:______________________________ 8134. If the claimant is required to execute a waiver and release in exchange for, or in order to induce payment of, a progress payment and the claimant asserts in the waiver that the claimant has, in fact, been paid the progress payment, the waiver and release shall be null, void, and unenforceable unless it is in substantially the following form, with the text of the "Notice to Claimant" in at least as large a type as the largest type otherwise in the form: UNCONDITIONAL WAIVER AND RELEASE ON PROGRESS PAYMENT NOTICE TO CLAIMANT: THIS DOCUMENT WAIVES AND RELEASES LIEN, STOP PAYMENT NOTICE, AND PAYMENT BOND RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID. IF YOU HAVE NOT BEEN PAID, USE A CONDITIONAL WAIVER AND RELEASE FORM. Identifying Information Name of Claimant:_______________________________ Name of Customer:_______________________________ Job Location:___________________________________ Owner:__________________________________________ Through Date:___________________________________ Unconditional Waiver and Release This document waives and releases lien, stop payment notice, and payment bond rights the claimant has for labor and service provided, and equipment and material delivered, to the customer on this job through the Through Date of this document. Rights based upon labor or service provided, or equipment or material delivered, pursuant to a written change order that has been fully executed by the parties prior to the date that this document is signed by the claimant, are waived and released by this document, unless listed as an Exception below. The claimant has received the following progress payment: $_____________________________ Exceptions This document does not affect any of the following: (1) Retentions. (2) Extras for which the claimant has not received payment. (3) Contract rights, including (A) a right based on rescission, abandonment, or breach of contract, and (B) the right to recover compensation for work not compensated by the payment. Signature Claimant's Signature:___________________________ Claimant's Title:_______________________________ Date of Signature:______________________________ 8136. If the claimant is required to execute a waiver and release in exchange for, or in order to induce payment of, a final payment and the claimant is not, in fact, paid in exchange for the waiver and release or a single payee check or joint payee check is given in exchange for the waiver and release, the waiver and release shall be null, void, and unenforceable unless it is in substantially the following form: CONDITIONAL WAIVER AND RELEASE ON FINAL PAYMENT NOTICE: THIS DOCUMENT WAIVES THE CLAIMANT'S LIEN, STOP PAYMENT NOTICE, AND PAYMENT BOND RIGHTS EFFECTIVE ON RECEIPT OF PAYMENT. A PERSON SHOULD NOT RELY ON THIS DOCUMENT UNLESS SATISFIED THAT THE CLAIMANT HAS RECEIVED PAYMENT. Identifying Information Name of Claimant:_______________________________ Name of Customer:_______________________________ Job Location:___________________________________ Owner:__________________________________________ Conditional Waiver and Release This document waives and releases lien, stop payment notice, and payment bond rights the claimant has for labor and service provided, and equipment and material delivered, to the customer on this job. Rights based upon labor or service provided, or equipment or material delivered, pursuant to a written change order that has been fully executed by the parties prior to the date that this document is signed by the claimant, are waived and released by this document, unless listed as an Exception below. This document is effective only on the claimant's receipt of payment from the financial institution on which the following check is drawn: Maker of Check:_________________________________ Amount of Check: $______________________________ Check Payable to:_______________________________ Exceptions This document does not affect any of the following: Disputed claims for extras in the amount of: $ _______________________ Signature Claimant's Signature:___________________________ Claimant's Title:_______________________________ Date of Signature:______________________________ 8138. If the claimant is required to execute a waiver and release in exchange for, or in order to induce payment of, a final payment and the claimant asserts in the waiver that the claimant has, in fact, been paid the final payment, the waiver and release shall be null, void, and unenforceable unless it is in substantially the following form, with the text of the "Notice to Claimant" in at least as large a type as the largest type otherwise in the form: UNCONDITIONAL WAIVER AND RELEASE ON FINAL PAYMENT NOTICE TO CLAIMANT: THIS DOCUMENT WAIVES AND RELEASES LIEN, STOP PAYMENT NOTICE, AND PAYMENT BOND RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID. IF YOU HAVE NOT BEEN PAID, USE A CONDITIONAL WAIVER AND RELEASE FORM. Identifying Information Name of Claimant:_______________________________ Name of Customer:_______________________________ Job Location:___________________________________ Owner:__________________________________________ Unconditional Waiver and Release This document waives and releases lien, stop payment notice, and payment bond rights the claimant has for all labor and service provided, and equipment and material delivered, to the customer on this job. Rights based upon labor or service provided, or equipment or material delivered, pursuant to a written change order that has been fully executed by the parties prior to the date that this document is signed by the claimant, are waived and released by this document, unless listed as an Exception below. The claimant has been paid in full. Exceptions This document does not affect the following: Disputed claims for extras in the amount of: $ ________________ Signature Claimant's Signature:___________________________ Claimant's Title:_______________________________ Date of Signature:______________________________ CHAPTER 4. BONDS 8150. The Bond and Undertaking Law (Chapter 2 (commencing with Section 995.010) of Title 14 of Part 2 of the Code of Civil Procedure) applies to a bond given under this part, except to the extent this part prescribes a different rule or is inconsistent. 8152. None of the following releases a surety from liability on a bond given under this part: (a) A change, alteration, or modification to a contract, plan, specification, or agreement for a work of improvement or for work provided for a work of improvement. (b) A change or modification to the terms of payment or an extension of the time for payment for a work of improvement. (c) A rescission or attempted rescission of a contract, agreement, or bond. (d) A condition precedent or subsequent in the bond purporting to limit the right of recovery of a claimant otherwise entitled to recover pursuant to a contract, agreement, or bond. (e) In the case of a bond given for the benefit of claimants, the fraud of a person other than the claimant seeking to recover on the bond. 8154. (a) A bond given under this part shall be construed most strongly against the surety and in favor of all persons for whose benefit the bond is given. (b) A surety is not released from liability to those for whose benefit the bond has been given by reason of a breach of the direct contract or on the part of any obligee named in the bond. (c) Except as otherwise provided by statute, the sole conditions of recovery on the bond are that the claimant is a person described in Article 1 (commencing with Section 8400) of Chapter 4 of Title 2, or in Section 9100, and has not been paid the full amount of the claim. TITLE 2. PRIVATE WORKS OF IMPROVEMENT CHAPTER 1. GENERAL PROVISIONS Article 1. Application of Title 8160. This title applies to a work of improvement that is not governed by Title 3 (commencing with Section 9000) of this part. Article 2. Construction Documents 8170. (a) A written direct contract shall provide a space for the owner to enter the following information: (1) The owner's name, address, and place of business, if any. (2) The name and address of the construction lender, if any. This paragraph does not apply to a home improvement contract or swimming pool contract subject to Article 10 (commencing with Section 7150) of Chapter 9 of Division 3 of the Business and Professions Code. (b) A written contract entered into between a direct contractor and subcontractor, or between subcontractors, shall provide a space for the name and address of the owner, direct contractor, and construction lender, if any. 8172. (a) A public entity that issues building permits shall, in its application form for a building permit, provide space and a designation for the applicant to enter the name, branch designation, if any, and address of the construction lender and shall keep the information on file open for public inspection during the regular business hours of the public entity. (b) If there is no known construction lender, the applicant shall note that fact in the designated space. (c) Failure of the applicant to indicate the name and address of the construction lender on the application does not relieve a person required to give the construction lender preliminary notice from that duty. 8174. (a) A mortgage, deed of trust, or other instrument securing a loan, any of the proceeds of which may be used for a work of improvement, shall bear the designation "Construction Trust Deed" prominently on its face and shall state all of the following: (1) The name and address of the construction lender. (2) The name and address of the owner of the real property described in the instrument. (3) A legal description of the real property that secures the loan and, if known, the street address of the property. (b) Failure to comply with subdivision (a) does not affect the validity of the mortgage, deed of trust, or other instrument. (c) Failure to comply with subdivision (a) does not relieve a person required to give preliminary notice from that duty. (d) The county recorder of the county in which the instrument is recorded shall indicate in the general index of the official records of the county that the instrument secures a construction loan. Article 3. Completion 8180. (a) For the purpose of this title, completion of a work of improvement occurs upon the occurrence of any of the following events: (1) Actual completion of the work of improvement. (2) Occupation or use by the owner accompanied by cessation of labor. (3) Cessation of labor for a continuous period of 60 days. (4) Recordation of a notice of cessation after cessation of labor for a continuous period of 30 days. (b) Notwithstanding subdivision (a), if a work of improvement is subject to acceptance by a public entity, completion occurs on acceptance. 8182. (a) An owner may record a notice of completion on or within 15 days after the date of completion of a work of improvement. (b) The notice of completion shall be signed and verified by the owner. (c) The notice shall comply with the requirements of Chapter 2 (commencing with Section 8100) of Title 1, and shall also include all of the following information: (1) If the notice is given only of completion of a contract for a particular portion of the work of improvement as provided in Section 8186, the name of the direct contractor under that contract and a general statement of the work provided pursuant to the contract. (2) If signed by the owner's successor in interest, the name and address of the successor's transferor. (3) The nature of the interest or estate of the owner. (4) The date of completion. An erroneous statement of the date of completion does not affect the effectiveness of the notice if the true date of completion is 15 days or less before the date of recordation of the notice. (d) A notice of completion that does not comply with the provisions of this section is not effective. (e) For the purpose of this section, "owner" means the owner who causes a building, improvement, or structure to be constructed, altered, or repaired, or that person's successor in interest at the date a notice of completion is recorded, whether the interest or estate of the owner be in fee, as vendee under a contract of purchase, as lessee, or other interest or estate less than the fee. Where the interest or estate is held by two or more persons as joint tenants or tenants in common, any one or more of the cotenants may be deemed to be the "owner" within the meaning of this section. 8184. A notice of completion in otherwise proper form, verified and containing the information required by this title, shall be accepted by the recorder for recording and is deemed duly recorded without acknowledgment. 8186. If a work of improvement is made pursuant to two or more direct contracts, each covering a portion of the work of improvement: (a) The owner may record a notice of completion of a direct contract for a portion of the work of improvement. On recordation of the notice of completion, for the purpose of Sections 8412 and 8414, a direct contractor is deemed to have completed the contract for which the notice of completion is recorded and a claimant other than a direct contractor is deemed to have ceased providing work. (b) If the owner does not record a notice of completion under this section, the period for recording a claim of lien is that provided in Sections 8412 and 8414. 8188. (a) An owner may record a notice of cessation if there has been a continuous cessation of labor on a work of improvement for at least 30 days prior to the recordation that continues through the date of the recordation. (b) The notice shall be signed and verified by the owner. (c) The notice shall comply with the requirements of Chapter 2 (commencing with Section 8100) of Title 1, and shall also include all of the following information: (1) The date on or about which labor ceased. (2) A statement that the cessation has continued until the recordation of the notice. (d) For the purpose of this section, "owner" means the owner who causes a building, improvement, or structure to be constructed, altered, or repaired, or that person's successor in interest at the date a notice of cessation is recorded, whether the interest or estate of the owner be in fee, as vendee under a contract of purchase, as lessee, or other interest or estate less than the fee. Where the interest or estate is held by two or more persons as joint tenants or tenants in common, any one or more of the cotenants may be deemed to be the "owner" within the meaning of this section. 8190. (a) An owner that records a notice of completion or cessation shall, within 10 days of the date the notice of completion or cessation is filed for record, give a copy of the notice to all of the following persons: (1) A direct contractor. (2) A claimant that has given the owner preliminary notice. (b) The copy of the notice shall be given in compliance with the requirements of Chapter 2 (commencing with Section 8100) of Title 1. (c) If the owner fails to give notice to a person as required by subdivision (a), the notice is ineffective to shorten the time within which that person may record a claim of lien under Sections 8412 and 1. 8414. The ineffectiveness of the notice is the sole liability of the 2. owner for failure to give notice to a person under subdivision (a). (d) For the purpose of this section, "owner" means a person who has an interest in real property, or the person's successor in interest on the date a notice of completion or notice of cessation is recorded, who causes a building, improvement, or structure, to be constructed, altered, or repaired on the property. If the property is owned by two or more persons as joint tenants or tenants in common, any one or more of the cotenants may be deemed to be the "owner" within the meaning of this section. However, this section does not apply to any of the following owners: (1) A person that occupies the real property as a personal residence, if the dwelling contains four or fewer residential units. (2) A person that has a security interest in the property. (3) A person that obtains an interest in the property pursuant to a transfer described in subdivision (b), (c), or (d) of Section 1102.2. CHAPTER 2. PRELIMINARY NOTICE 8200. (a) Except as otherwise provided by statute, before recording a lien claim, giving a stop payment notice, or asserting a claim against a payment bond, a claimant shall give preliminary notice to the following persons: (1) The owner or reputed owner. (2) The direct contractor or reputed direct contractor to which the claimant provides work, either directly or through one or more subcontractors. (3) The construction lender or reputed construction lender, if any. (b) The notice shall comply with the requirements of Chapter 2 (commencing with Section 8100) of Title 1. (c) Compliance with this section is a necessary prerequisite to the validity of a lien claim or stop payment notice under this title. (d) Compliance with this section or with Section 8612 is a necessary prerequisite to the validity of a claim against a payment bond under this title. (e) Notwithstanding the foregoing subdivisions: (1) A laborer is not required to give preliminary notice. (2) A claimant with a direct contractual relationship with an owner or reputed owner is required to give preliminary notice only to the construction lender or reputed construction lender, if any. 8202. (a) The preliminary notice shall comply with the requirements of Section 8102, and shall also include: (1) A general description of the work to be provided. (2) An estimate of the total price of the work provided and to be provided. (3) The following statement in boldface type: NOTICE TO PROPERTY OWNER EVEN THOUGH YOU HAVE PAID YOUR CONTRACTOR IN FULL, if the person or firm that has given you this notice is not paid in full for labor, service, equipment, or material provided or to be provided to your construction project, a lien may be placed on your property. Foreclosure of the lien may lead to loss of all or part of your property. You may wish to protect yourself against this by (1) requiring your contractor to provide a signed release by the person or firm that has given you this notice before making payment to your contractor, or (2) any other method that is appropriate under the circumstances. This notice is required by law to be served by the undersigned as a statement of your legal rights. This notice is not intended to reflect upon the financial condition of the contractor or the person employed by you on the construction project. If you record a notice of cessation or completion of your construction project, you must within 10 days after recording, send a copy of the notice of completion to your contractor and the person or firm that has given you this notice. The notice must be sent by registered or certified mail. Failure to send the notice will extend the deadline to record a claim of lien. You are not required to send the notice if you are a residential homeowner of a dwelling containing four or fewer units. (b) If preliminary notice is given by a subcontractor that has not paid all compensation due to a laborer, the notice shall include the name and address of the laborer and any person or entity described in subdivision (b) of Section 8024 to which payments are due. (c) If an invoice for material or certified payroll contains the information required by this section and Section 8102, a copy of the invoice or payroll, given in compliance with the requirements of Chapter 2 (commencing with Section 8100) of Title 1, is sufficient. 8204. (a) A preliminary notice shall be given not later than 20 days after the claimant has first furnished work on the work of improvement. If work has been provided by a claimant who did not give a preliminary notice, that claimant shall not be precluded from giving a preliminary notice at any time thereafter. The claimant shall, however, be entitled to record a lien, give a stop payment notice, and assert a claim against a payment bond only for work performed within 20 days prior to the service of the preliminary notice, and at any time thereafter. (b) A design professional who has furnished services for the design of the work of improvement and who gives a preliminary notice not later than 20 days after the work of improvement has commenced shall be deemed to have complied with Section 8200 with respect to the design services furnished, or to be furnished. 8206. (a) Except as provided in subdivision (b), a claimant need give only one preliminary notice to each person to which notice must be given under this chapter with respect to all work provided by the claimant for a work of improvement. (b) If a claimant provides work pursuant to contracts with more than one subcontractor, the claimant shall give a separate preliminary notice with respect to work provided pursuant to each contract. (c) A preliminary notice that contains a general description of work provided by the claimant through the date of the notice also covers work provided by the claimant after the date of the notice whether or not they are within the scope of the general description contained in the notice. 8208. A direct contractor shall make available to any person seeking to give preliminary notice the following information: (a) The name and address of the owner. (b) The name and address of the construction lender, if any. 8210. If one or more construction loans are obtained after commencement of a work of improvement, the owner shall give notice of the name and address of the construction lender or lenders to each person that has given the owner preliminary notice. 8212. An agreement made or entered into by an owner whereby the owner agrees to waive the rights conferred on the owner by this chapter is void and unenforceable. 8214. (a) Each person who has served a preliminary notice may file the preliminary notice with the county recorder. A preliminary notice filed pursuant to this section shall comply with the requirements of Section 8102. (b) Upon the acceptance for recording of a notice of completion or notice of cessation the county recorder shall mail to those persons who have filed a preliminary notice, notification that a notice of completion or notice of cessation has been recorded on the property, and shall affix the date that the notice of completion or notice of cessation was recorded with the county recorder. The notification given by the county recorder under this section is not governed by the requirements of Chapter 2 (commencing with Section 8100) of Title 1. (c) The failure of the county recorder to mail the notification to the person who filed a preliminary notice, or the failure of those persons to receive the notification or to receive complete notification, shall not affect the period within which a claim of lien is required to be recorded. However, the county recorder shall make a good faith effort to mail notification to those persons who have filed the preliminary notice under this section and to do so within five days after the recording of a notice of completion or notice of cessation. (d) The county recorder may cause to be destroyed all documents filed pursuant to this section, two years after the date of filing. (e) The preliminary notice that a person may file pursuant to this section is for the limited purpose of facilitating the mailing of notice by the county recorder of recorded notices of completion and notices of cessation. The notice that is filed is not a recordable document and shall not be entered into those official records of the county which by law impart constructive notice. Notwithstanding any other provision of law, the index maintained by the recorder of filed preliminary notices shall be separate and distinct from those indexes maintained by the county recorder of those official records of the county which by law impart constructive notice. The filing of a preliminary notice with the county recorder does not give rise to any actual or constructive notice with respect to any party of the existence or contents of a filed preliminary notice nor to any duty of inquiry on the part of any party as to the existence or contents of that notice. 8216. If the contract of any subcontractor on a particular work of improvement provides for payment to the subcontractor of more than four hundred dollars ($400), the failure of that subcontractor, licensed under the Contractors' State License Law (Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code), to give the notice provided for in this chapter, constitutes grounds for disciplinary action under the Contractors' State License Law. CHAPTER 3. DESIGN PROFESSIONALS LIEN 8300. For purposes of this chapter, a "design professional" is a person described in Section 8014 who provides services pursuant to a written contract with a landowner for the design, engineering, or planning of a work of improvement. 8302. (a) A design professional has, from the date of recordation of a claim of lien under this chapter, a lien on the site notwithstanding the absence of commencement of the planned work of improvement, if the landowner who contracted for the design professional's services is also the owner of the site at the time of recordation of the claim of lien. (b) The lien of the design professional is for the amount of the design professional's fee for services provided under the contract or the reasonable value of those services, whichever is less. The amount of the lien is reduced by the amount of any deposit or prior payment under the contract. (c) A design professional may not record a claim of lien, and a lien may not be created, under this chapter unless a building permit or other governmental approval in furtherance of the work of improvement has been obtained in connection with or utilizing the services provided by the design professional. 8304. A design professional is not entitled to a lien under this chapter unless all of the following conditions are satisfied: (a) The work of improvement for which the design professional provided services has not commenced. (b) The landowner defaults in a payment required under the contract or refuses to pay the demand of the design professional made under the contract. (c) Not less than 10 days before recording a claim of lien, the design professional gives the landowner notice making a demand for payment, and stating that a default has occurred under the contract and the amount of the default. (d) The design professional records a claim of lien. The claim of lien shall include all of the following information: (1) The name of the design professional. (2) The amount of the claim. (3) The current owner of record of the site. (4) A legal description of the site. (5) Identification of the building permit or other governmental approval for the work of improvement. 8306. (a) On recordation of the claim of lien, a lien is created in favor of the named design professional. (b) The lien automatically expires and is null and void and of no further force or effect on the occurrence of either of the following events: (1) The commencement of the work of improvement for which the design professional provided services. (2) The expiration of 90 days after recording the claim of lien, unless the design professional commences an action to enforce the lien within that time. (c) If the landowner partially or fully satisfies the lien, the design professional shall execute and record a document that evidences a partial or full satisfaction and release of the lien, as applicable. 8308. (a) Except as provided in subdivision (b), no provision of this part applies to a lien created under this chapter. (b) The following provisions of this part apply to a lien created under this chapter: (1) This chapter. (2) Article 1 (commencing with Section 8000) of Chapter 1 of Title 1. (3) Section 8424. (4) Article 6 (commencing with Section 8460) of Chapter 4. (5) Article 7 (commencing with Section 8480) of Chapter 4. (6) Article 8 (commencing with Section 8490) of Chapter 4. 8310. This chapter does not affect the ability of a design professional to obtain a lien for a work of improvement under Section 8400. 8312. A design professional shall record a claim of lien under this chapter no later than 90 days after the design professional knows or has reason to know that the work of improvement will not be commenced. 8314. The creation of a lien under this chapter does not affect the ability of the design professional to pursue other remedies. 8316. (a) No lien created under this chapter affects or takes priority over the interest of record of a purchaser, lessee, or encumbrancer, if the interest of the purchaser, lessee, or encumbrancer in the real property was duly recorded before recordation of the claim of lien. (b) No lien created under this chapter affects or takes priority over an encumbrance of a construction lender that funds the loan for the work of improvement for which the design professional provided services. 8318. A design professional may not obtain a lien under this chapter for services provided for a work of improvement relating to a single-family, owner-occupied residence for which the expected construction cost is less than one hundred thousand dollars ($100,000). 8319. (a) A design professional may convert a recorded design professional lien to a mechanics lien if all of the following requirements are met: (1) The design professional lien expires pursuant to paragraph (1) of subdivision (b) of Section 8306. (2) The design professional lien remains fully or partially unpaid. (3) Within 30 days of the expiration of the design professional lien pursuant to paragraph (1) of subdivision (b) of Section 8306, the design professional records a mechanics lien for the amount of the unpaid design professional lien. (4) The recorded mechanics lien states that it is a converted design professional lien but shall be recorded and enforced as a mechanics lien, except the design professional need not provide a preliminary notice to enforce this mechanics lien. This mechanics lien shall be effective as of the date of recordation of this mechanics lien and shall be given priority pursuant to the provisions of Section 8450. (b) This section shall not apply if a design professional lien expires pursuant to paragraph (2) of subdivision (b) of Section 8306. CHAPTER 4. MECHANICS LIEN Article 1. Who is Entitled to Lien 8400. A person that provides work authorized for a work of improvement, including, but not limited to, the following persons, has a lien right under this chapter: (a) Direct contractor. (b) Subcontractor. (c) Material supplier. (d) Equipment lessor. (e) Laborer. (f) Design professional. 8402. A person that provides work authorized for a site improvement has a lien right under this chapter. 8404. Work is authorized for a work of improvement or for a site improvement in any of the following circumstances: (a) It is provided at the request of or agreed to by the owner. (b) It is provided or authorized by a direct contractor, subcontractor, architect, project manager, or other person having charge of all or part of the work of improvement or site improvement. Article 2. Conditions to Enforcing a Lien 8410. A claimant may enforce a lien only if the claimant has given preliminary notice to the extent required by Chapter 2 (commencing with Section 8200) and made proof of notice. 8412. A direct contractor may not enforce a lien unless the contractor records a claim of lien after the contractor completes the direct contract, and before the earlier of the following times: (a) Ninety days after completion of the work of improvement. (b) Sixty days after the owner records a notice of completion or cessation. 8414. A claimant other than a direct contractor may not enforce a lien unless the claimant records a claim of lien within the following times: (a) After the claimant ceases to provide work. (b) Before the earlier of the following times: (1) Ninety days after completion of the work of improvement. (2) Thirty days after the owner records a notice of completion or cessation. 8416. (a) A claim of mechanics lien shall be a written statement, signed and verified by the claimant, containing all of the following: (1) A statement of the claimant's demand after deducting all just credits and offsets. (2) The name of the owner or reputed owner, if known. (3) A general statement of the kind of work furnished by the claimant. (4) The name of the person by whom the claimant was employed or to whom the claimant furnished work. (5) A description of the site sufficient for identification. (6) The claimant's address. (7) A proof of service affidavit completed and signed by the person serving a copy of the claim of mechanics lien pursuant to subdivision (c). The affidavit shall show the date, place, and manner of service, and facts showing that the service was made in accordance with this section. The affidavit shall show the name and address of the person or persons upon whom the copy of the claim of mechanics lien was served, and, if appropriate, the title or capacity in which he or she was served. (8) The following statement, printed in at least 10-point boldface type. The letters of the last sentence shall be printed in uppercase type, excepting the Internet Web site address of the Contractors' State License Board, which shall be printed in lowercase type: ""NOTICE OF MECHANICS LIEN ATTENTION! Upon the recording of the enclosed MECHANICS LIEN with the county recorder's office of the county where the property is located, your property is subject to the filing of a legal action seeking a court-ordered foreclosure sale of the real property on which the lien has been recorded. That legal action must be filed with the court no later than 90 days after the date the mechanics lien is recorded. The party identified in the enclosed mechanics lien may have provided labor or materials for improvements to your property and may not have been paid for these items. You are receiving this notice because it is a required step in filing a mechanics lien foreclosure action against your property. The foreclosure action will seek a sale of your property in order to pay for unpaid labor, materials, or improvements provided to your property. This may affect your ability to borrow against, refinance, or sell the property until the mechanics lien is released. BECAUSE THE LIEN AFFECTS YOUR PROPERTY, YOU MAY WISH TO SPEAK WITH YOUR CONTRACTOR IMMEDIATELY, OR CONTACT AN ATTORNEY, OR FOR MORE INFORMATION ON MECHANICS LIENS GO TO THE CONTRACTORS' STATE LICENSE BOARD WEB SITE AT www.cslb.ca.gov.'' (b) A claim of mechanics lien in otherwise proper form, verified and containing the information required in subdivision (a), shall be accepted by the recorder for recording and shall be deemed duly recorded without acknowledgment. (c) A copy of the claim of mechanics lien, which includes the Notice of Mechanics Lien required by paragraph (8) of subdivision (a), shall be served on the owner or reputed owner. Service shall be made as follows: (1) For an owner or reputed owner to be notified who resides in or outside this state, by registered mail, certified mail, or first-class mail, evidenced by a certificate of mailing, postage prepaid, addressed to the owner or reputed owner at the owner's or reputed owner's residence or place of business address or at the address shown by the building permit on file with the authority issuing a building permit for the work, or as otherwise provided in Section 8174. (2) If the owner or reputed owner cannot be served by this method, then the copy of the claim of mechanics lien may be given by registered mail, certified mail, or first-class mail, evidenced by a certificate of mailing, postage prepaid, addressed to the construction lender or to the original contractor. (d) Service of the copy of the claim of mechanics lien by registered mail, certified mail, or first-class mail, evidenced by a certificate of mailing, postage prepaid, is complete at the time of the deposit of that first-class, certified, or registered mail. (e) Failure to serve the copy of the claim of mechanics lien as prescribed by this section, including the Notice of Mechanics Lien required by paragraph (8) of subdivision (a), shall cause the claim of mechanics lien to be unenforceable as a matter of law. 8422. (a) Except as provided in subdivisions (b) and (c), erroneous information contained in a claim of lien relating to the claimant's demand, credits and offsets deducted, the work provided, or the description of the site, does not invalidate the claim of lien. (b) Erroneous information contained in a claim of lien relating to the claimant's demand, credits and offsets deducted, or the work provided, invalidates the claim of lien if the court determines either of the following: (1) The claim of lien was made with intent to defraud. (2) An innocent third party, without notice, actual or constructive, became the bona fide owner of the property after recordation of the claim of lien, and the claim of lien was so deficient that it did not put the party on further inquiry in any manner. (c) Any person who shall willfully include in a claim of lien labor, services, equipment, or materials not furnished for the property described in the claim, shall thereby forfeit the person's lien. 8424. (a) An owner of real property or an owner of any interest in real property subject to a recorded claim of lien, or a direct contractor or subcontractor affected by the claim of lien, that disputes the correctness or validity of the claim may obtain release of the real property from the claim of lien by recording a lien release bond. The principal on the bond may be the owner of the property, the direct contractor, or the subcontractor. (b) The bond shall be conditioned on payment of any judgment and costs the claimant recovers on the lien. The bond shall be in an amount equal to 125 percent of the amount of the claim of lien or 125 percent of the amount allocated in the claim of lien to the real property to be released. The bond shall be executed by an admitted surety insurer. (c) The bond may be recorded either before or after commencement of an action to enforce the lien. On recordation of the bond, the real property is released from the claim of lien and from any action to enforce the lien. (d) A person that obtains and records a lien release bond shall give notice to the claimant. The notice shall comply with the requirements of Chapter 2 (commencing with Section 8100) of Title 1 and shall include a copy of the bond. Failure to give the notice required by this section does not affect the validity of the bond, but the statute of limitations for an action on the bond is tolled until notice is given. The claimant shall commence an action on the bond within six months after notice is given. Article 3. Amount of Lien 8430. (a) The lien is a direct lien for the lesser of the following amounts: (1) The reasonable value of the work provided by the claimant. (2) The price agreed to by the claimant and the person that contracted for the work. (b) The lien is not limited in amount by the contract price foLegal definition
Unconditional Waiver and Release Upon Final Payment
Contractors - Construction Liens - California
California Code CALIFORNIA CIVIL CODE Division 4. General Provisions Part 6. Works of Improvement Title 1. Works of Improvement Generally Chapter 1. General Provisions Article 1. Definitions PART 6. WORKS OF IMPROVEMENT TITLE 1. WORKS OF IMPROVEMENT GENERALLY CHAPTER 1. GENERAL PROVISIONS Article 1. Definitions 8000. Unless the provision or context otherwise requires, the definitions in this article govern the construction of this part. 8002. "Admitted surety insurer" has the meaning provided in Section 995.120 of the Code of Civil Procedure. 8004. "Claimant" means a person that has a right under this part to record a claim of lien, give a stop payment notice, or assert a claim against a payment bond, or do any combination of the foregoing. 8006. "Construction lender" means either of the following: (a) A mortgagee or beneficiary under a deed of trust lending funds with which the cost of all or part of a work of improvement is to be paid, or the assignee or successor in interest of the mortgagee or beneficiary. (b) An escrow holder or other person holding funds provided by an owner, lender, or another person as a fund for(from)with which the cost of all or part of a work of improvement is to be paid. 8008. "Contract" means an agreement that provides for all or part of a work of improvement. 8010. "Contract price" means the price agreed to in a direct contract for a work of improvement. 8012. "Contractor" includes a direct contractor, subcontractor, or both. This section does not apply to Sections 8018 and 8046. 8014. "Design professional" means a person licensed as an architect pursuant to Chapter 3 (commencing with Section 5500) of Division 3 of the Business and Professions Code, licensed as a landscape architect pursuant to Chapter 3.5 (commencing with Section 5615) of Division 3 of the Business and Professions Code, registered as a professional engineer pursuant to Chapter 7 (commencing with Section 6700) of Division 3 of the Business and Professions Code, or licensed as a land surveyor pursuant to Chapter 15 (commencing with Section 8700) of Division 3 of the Business and Professions Code. 8016. "Direct contract" means a contract between an owner and a direct contractor that provides for all or part of a work of improvement. 8018. "Direct contractor" means a contractor that has a direct contractual relationship with an owner. A reference in another statute to a "prime contractor" in connection with the provisions in this part means a "direct contractor." 8020. For the purposes of Title 3 (commencing with Section 9000), "funds" means warrant, check, money, or bonds (if bonds are to be issued in payment of the public works contract). 8022. "Labor, service, equipment, or material" includes, but is not limited to, labor, skills, services, material, supplies, equipment, appliances, power, and surveying, provided for a work of improvement. 8024. (a) "Laborer" means a person who, acting as an employee, performs labor upon, or bestows skill or other necessary services on, a work of improvement. (b) "Laborer" includes a person or entity to which a portion of a laborer's compensation for a work of improvement, including, but not limited to, employer payments described in Section 1773.1 of the Labor Code and implementing regulations, is paid by agreement with that laborer or the collective bargaining agent of that laborer. (c) A person or entity described in subdivision (b) that has standing under applicable law to maintain a direct legal action, in its own name or as an assignee, to collect any portion of compensation owed for a laborer for a work of improvement, shall have standing to enforce any rights or claims of the laborer under this part, to the extent of the compensation agreed to be paid to the person or entity for labor on that improvement. This subdivision is intended to give effect to the longstanding public policy of this state to protect the entire compensation of a laborer on a work of improvement, regardless of the form in which that compensation is to be paid. 8026. "Lien" means a lien under Title 2 (commencing with Section 8160) and includes a lien of a design professional under Section 8302, a lien for a work of improvement under Section 8400, and a lien for a site improvement under Section 8402. 8028. "Material supplier" means a person that provides material or supplies to be used or consumed in a work of improvement. 8030. (a) For the purposes of Title 2 (commencing with Section 8160), "payment bond" means a bond given under Section 8600. (b) For the purposes of Title 3 (commencing with Section 9000), "payment bond" means a bond required by Section 9550. 8032. "Person" means an individual, corporation, public entity, business trust, estate, trust, partnership, limited liability company, association, or other entity. 8034. (a) For the purposes of Title 2 (commencing with Section 8160), "preliminary notice" means the notice provided for in Chapter 2 (commencing with Section 8200) of Title 2. (b) For the purposes of Title 3 (commencing with Section 9000), "preliminary notice" means the notice provided for in Chapter 3 (commencing with Section 9300) of Title 3. 8036. "Public entity" means the state, Regents of the University of California, a county, city, district, public authority, public agency, and any other political subdivision or public corporation in the state. 8038. "Public works contract" has the meaning provided in Section 1101 of the Public Contract Code. 8040. "Site" means the real property on which a work of improvement is situated or planned. 8042. "Site improvement" means any of the following work on real property: (a) Demolition or removal of improvements, trees, or other vegetation. (b) Drilling test holes. (c) Grading, filling, or otherwise improving the real property or a street, highway, or sidewalk in front of or adjoining the real property. (d) Construction or installation of sewers or other public utilities. (e) Construction of areas, vaults, cellars, or rooms under sidewalks. (f) Any other work or improvements in preparation of the site for a work of improvement. 8044. (a) (1) For the purposes of Title 2 (commencing with Section 8160), "stop payment notice" means the notice given by a claimant under Chapter 5 (commencing with Section 8500) of Title 2. (2) A stop payment notice given under Title 2 (commencing with Section 8160) may be bonded or unbonded. A "bonded stop payment notice" is a notice given with a bond under Section 8532. An "unbonded stop payment notice" is a notice not given with a bond under Section 8532. (3) Except to the extent Title 2 (commencing with Section 8160) distinguishes between a bonded and an unbonded stop payment notice, a reference in that title to a stop payment notice includes both a bonded and an unbonded notice. (b) For the purposes of Title 3 (commencing with Section 9000), "stop payment notice" means the notice given by a claimant under Chapter 4 (commencing with Section 9350) of Title 3. (c) A reference in another statute to a "stop notice" in connection with the remedies provided in this part means a stop payment notice. 8046. "Subcontractor" means a contractor that does not have a direct contractual relationship with an owner. The term includes a contractor that has a contractual relationship with a direct contractor or with another subcontractor. 8048. "Work" means labor, service, equipment, or material provided to a work of improvement. 8050. (a) "Work of improvement" includes, but is not limited to: (1) Construction, alteration, repair, demolition, or removal, in whole or in part, of, or addition to, a building, wharf, bridge, ditch, flume, aqueduct, well, tunnel, fence, machinery, railroad, or road. (2) Seeding, sodding, or planting of real property for landscaping purposes. (3) Filling, leveling, or grading of real property. (b) Except as otherwise provided in this part, "work of improvement" means the entire structure or scheme of improvement as a whole, and includes site improvement. Article 2. Miscellaneous Provisions 8052. (a) This part is operative on July 1, 2012. (b) Notwithstanding subdivision (a), the effectiveness of a notice given or other action taken on a work of improvement before July 1, 2012, is governed by the applicable law in effect before July 1, 2012, and not by this part. (c) A provision of this part, insofar as it is substantially the same as a previously existing provision relating to the same subject matter, shall be construed as a restatement and continuation thereof and not as a new enactment. 8054. (a) This part does not apply to a transaction governed by the Oil and Gas Lien Act (Chapter 2.5 (commencing with Section 1203.50) of Title 4 of Part 3 of the Code of Civil Procedure). (b) This part does not apply to or change improvement security under the Subdivision Map Act (Division 2 (commencing with Section 66410) of Title 7 of the Government Code). (c) This part does not apply to a transaction governed by Sections 20457 to 20464, inclusive, of the Public Contract Code. 8056. Except as otherwise provided in this part, Part 2 (commencing with Section 307) of the Code of Civil Procedure provides the rules of practice in proceedings under this part. 8058. For purposes of this part, "day" means a calendar day. 8060. (a) If this part provides for filing a contract, plan, or other paper with the county recorder, the provision is satisfied by filing the paper in the office of the county recorder of the county in which the work of improvement or part of it is situated. (b) If this part provides for recording a notice, claim of lien, release of lien, payment bond, or other paper, the provision is satisfied by filing the paper for record in the office of the county recorder of the county in which the work of improvement or part of it is situated. (c) The county recorder shall number, index, and preserve a contract, plan, or other paper presented for filing under this part, and shall number, index, and transcribe into the official records, in the same manner as a conveyance of real property, a notice, claim of lien, payment bond, or other paper recorded under this part. (d) The county recorder shall charge and collect the fees provided in Article 5 (commencing with Section 27360) of Chapter 6 of Part 3 of Division 2 of Title 3 of the Government Code for performing duties under this section. 8062. No act of an owner in good faith and in compliance with a provision of this part shall be construed to prevent a direct contractor's performance of the contract, or exonerate a surety on a performance or payment bond. 8064. An owner may give a notice or execute or file a document under this part on behalf of a co-owner if the owner acts on the co-owner's behalf and includes in the notice or document the name and address of the co-owner on whose behalf the owner acts. 8066. An act that may be done by or to a person under this part may be done by or to the person's agent to the extent the act is within the scope of the agent's authority. CHAPTER 2. NOTICE 8100. Notice under this part shall be in writing. Writing includes printing and typewriting. 8102. (a) Notice under this part shall, in addition to any other information required by statute for that type of notice, include all of the following information to the extent known to the person giving the notice: (1) The name and address of the owner or reputed owner. (2) The name and address of the direct contractor. (3) The name and address of the construction lender, if any. (4) A description of the site sufficient for identification, including the street address of the site, if any. If a sufficient legal description of the site is given, the effectiveness of the notice is not affected by the fact that the street address is erroneous or is omitted. (5) The name, address, and relationship to the parties of the person giving the notice. (6) If the person giving the notice is a claimant: (A) A general statement of the work provided. (B) The name of the person to or for whom the work is provided. (C) A statement or estimate of the claimant's demand, if any, after deducting all just credits and offsets. (b) Notice is not invalid by reason of any variance from the requirements of this section if the notice is sufficient to substantially inform the person given notice of the information required by this section and other information required in the notice. 8104. (a) A direct contractor or subcontractor on a work of improvement governed by this part that employs a laborer and fails to pay the full compensation due the laborer, including any employer payments described in Section 1773.1 of the Labor Code and implementing regulations, shall not later than the date the compensation became delinquent, give the laborer, the laborer's bargaining representative, if any, the construction lender or reputed construction lender, if any, and the owner or reputed owner, notice that includes all of the following information, in addition to the information required by Section 8102: (1) The name and address of the laborer, and of any person or entity described in subdivision (b) of Section 8024 to which employer payments are due. (2) The total number of straight time and overtime hours worked by the laborer on each job. (3) The amount then past due and owing. (b) Failure to give the notice required by subdivision (a) constitutes grounds for disciplinary action under the Contractors' State License Law, Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code. 8106. Except as otherwise provided by statute, notice under this part shall be given by any of the following means: (a) Personal delivery. (b) Mail in the manner provided in Section 8110. (c) Leaving the notice and mailing a copy in the manner provided in Section 415.20 of the Code of Civil Procedure for service of summons and complaint in a civil action. 8108. Except as otherwise provided by this part, notice under this part shall be given to the person to be notified at the person's residence, the person's place of business, or at any of the following addresses: (a) If the person to be notified is an owner other than a public entity, the owner's address shown on the direct contract, the building permit, or a construction trust deed. (b) If the person to be notified is a public entity, the office of the public entity or another address specified by the public entity in the contract or elsewhere for service of notices, papers, and other documents. (c) If the person to be notified is a construction lender, the construction lender's address shown on the construction loan agreement or construction trust deed. (d) If the person to be notified is a direct contractor or a subcontractor, the contractor's address shown on the building permit, on the contractor's contract, or on the records of the Contractors' State License Board. (e) If the person to be notified is a claimant, the claimant's address shown on the claimant's contract, preliminary notice, claim of lien, stop payment notice, or claim against a payment bond, or on the records of the Contractors' State License Board. (f) If the person to be notified is a surety on a bond, the surety' s address shown on the bond for service of notices, papers, and other documents, or on the records of the Department of Insurance. 8110. Except as otherwise provided by this part, notice by mail under this part shall be given by registered or certified mail, express mail, or overnight delivery by an express service carrier. 8114. A notice required by this part to be posted shall be displayed in a conspicuous location at the site. 8116. Notice under this part is complete and deemed to have been given at the following times: (a) If given by personal delivery, when delivered. (b) If given by mail, when deposited in the mail or with an express service carrier in the manner provided in Section 1013 of the Code of Civil Procedure. (c) If given by leaving the notice and mailing a copy in the manner provided in Section 415.20 of the Code of Civil Procedure for service of summons in a civil action, five days after mailing. (d) If given by posting, when displayed. (e) If given by recording, when recorded in the office of the county recorder. 8118. (a) Proof that notice was given to a person in the manner required by this part shall be made by a proof of notice declaration that states all of the following: (1) The type or description of the notice given. (2) The date, place, and manner of notice, and facts showing that notice was given in the manner required by statute. (3) The name and address of the person to which notice was given, and, if appropriate, the title or capacity in which the person was given notice. (b) If the notice is given by mail, the declaration shall be accompanied by one of the following: (1) Documentation provided by the United States Postal Service showing that payment was made to mail the notice using registered or certified mail, or express mail. (2) Documentation provided by an express service carrier showing that payment was made to send the notice using an overnight delivery service. (3) A return receipt, delivery confirmation, signature confirmation, tracking record, or other proof of delivery or attempted delivery provided by the United States Postal Service, or a photocopy of the record of delivery and receipt maintained by the United States Postal Service, showing the date of delivery and to whom delivered, or in the event of nondelivery, by the returned envelope itself. (4) A tracking record or other documentation provided by an express service carrier showing delivery or attempted delivery of the notice. CHAPTER 3. WAIVER AND RELEASE 8120. The provisions of this chapter apply to a work of improvement governed by this part. 8122. An owner, direct contractor, or subcontractor may not, by contract or otherwise, waive, affect, or impair any other claimant's rights under this part, whether with or without notice, and any term of a contract that purports to do so is void and unenforceable unless and until the claimant executes and delivers a waiver and release under this article. 8124. A claimant's waiver and release does not release the owner, construction lender, or surety on a payment bond from a lien or claim unless both of the following conditions are satisfied: (a) The waiver and release is in substantially the form provided in this article and is signed by the claimant. (b) If the release is a conditional release, there is evidence of payment to the claimant. Evidence of payment may be either of the following: (1) The claimant's endorsement on a single or joint payee check that has been paid by the financial institution on which it was drawn. (2) Written acknowledgment of payment by the claimant. 8126. An oral or written statement purporting to waive, release, impair or otherwise adversely affect a lien or claim is void and unenforceable and does not create an estoppel or impairment of the lien or claim unless either of the following conditions is satisfied: (a) The statement is pursuant to a waiver and release under this article. (b) The claimant has actually received payment in full for the claim. 8128. (a) A claimant may reduce the amount of, or release in its entirety, a stop payment notice. The reduction or release shall be in writing and may be given in a form other than a waiver and release form provided in this article. (b) The writing shall identify whether it is a reduction of the amount of the stop payment notice, or a release of the notice in its entirety. If the writing is a reduction, it shall state the amount of the reduction, and the amount to remain withheld after the reduction. (c) A claimant's reduction or release of a stop payment notice has the following effect: (1) The reduction or release releases the claimant's right to enforce payment of the claim stated in the notice to the extent of the reduction or release. (2) The reduction or release releases the person given the notice from the obligation to withhold funds pursuant to the notice to the extent of the reduction or release. (3) The reduction or release does not preclude the claimant from giving a subsequent stop payment notice that is timely and proper. (4) The reduction or release does not release any right of the claimant other than the right to enforce payment of the claim stated in the stop payment notice to the extent of the reduction or release. 8130. This article does not affect the enforceability of either an accord and satisfaction concerning a good faith dispute or an agreement made in settlement of an action pending in court if the accord and satisfaction or agreement and settlement make specific reference to the lien or claim. 8132. If a claimant is required to execute a waiver and release in exchange for, or in order to induce payment of, a progress payment and the claimant is not, in fact, paid in exchange for the waiver and release or a single payee check or joint payee check is given in exchange for the waiver and release, the waiver and release shall be null, void, and unenforceable unless it is in substantially the following form: CONDITIONAL WAIVER AND RELEASE ON PROGRESS PAYMENT NOTICE: THIS DOCUMENT WAIVES THE CLAIMANT'S LIEN, STOP PAYMENT NOTICE, AND PAYMENT BOND RIGHTS EFFECTIVE ON RECEIPT OF PAYMENT. A PERSON SHOULD NOT RELY ON THIS DOCUMENT UNLESS SATISFIED THAT THE CLAIMANT HAS RECEIVED PAYMENT. Identifying Information Name of Claimant:_______________________________ Name of Customer:_______________________________ Job Location:___________________________________ Owner:__________________________________________ Through Date:___________________________________ Conditional Waiver and Release This document waives and releases lien, stop payment notice, and payment bond rights the claimant has for labor and service provided, and equipment and material delivered, to the customer on this job through the Through Date of this document. Rights based upon labor or service provided, or equipment or material delivered, pursuant to a written change order that has been fully executed by the parties prior to the date that this document is signed by the claimant, are waived and released by this document, unless listed as an Exception below. This document is effective only on the claimant's receipt of payment from the financial institution on which the following check is drawn: Maker of Check:_________________________________ Amount of Check: $______________________________ Check Payable to:_______________________________ Exceptions This document does not affect any of the following: (1) Retentions. (2) Extras for which the claimant has not received payment. (3) The following progress payments for which the claimant has previously given a conditional waiver and release but has not received payment: Date(s) of waiver and release:__________________ Amount(s) of unpaid progress payment(s): $______ (4) Contract rights, including (A) a right based on rescission, abandonment, or breach of contract, and (B) the right to recover compensation for work not compensated by the payment. Signature Claimant's Signature:___________________________ Claimant's Title:_______________________________ Date of Signature:______________________________ 8134. If the claimant is required to execute a waiver and release in exchange for, or in order to induce payment of, a progress payment and the claimant asserts in the waiver that the claimant has, in fact, been paid the progress payment, the waiver and release shall be null, void, and unenforceable unless it is in substantially the following form, with the text of the "Notice to Claimant" in at least as large a type as the largest type otherwise in the form: UNCONDITIONAL WAIVER AND RELEASE ON PROGRESS PAYMENT NOTICE TO CLAIMANT: THIS DOCUMENT WAIVES AND RELEASES LIEN, STOP PAYMENT NOTICE, AND PAYMENT BOND RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID. IF YOU HAVE NOT BEEN PAID, USE A CONDITIONAL WAIVER AND RELEASE FORM. Identifying Information Name of Claimant:_______________________________ Name of Customer:_______________________________ Job Location:___________________________________ Owner:__________________________________________ Through Date:___________________________________ Unconditional Waiver and Release This document waives and releases lien, stop payment notice, and payment bond rights the claimant has for labor and service provided, and equipment and material delivered, to the customer on this job through the Through Date of this document. Rights based upon labor or service provided, or equipment or material delivered, pursuant to a written change order that has been fully executed by the parties prior to the date that this document is signed by the claimant, are waived and released by this document, unless listed as an Exception below. The claimant has received the following progress payment: $_____________________________ Exceptions This document does not affect any of the following: (1) Retentions. (2) Extras for which the claimant has not received payment. (3) Contract rights, including (A) a right based on rescission, abandonment, or breach of contract, and (B) the right to recover compensation for work not compensated by the payment. Signature Claimant's Signature:___________________________ Claimant's Title:_______________________________ Date of Signature:______________________________ 8136. If the claimant is required to execute a waiver and release in exchange for, or in order to induce payment of, a final payment and the claimant is not, in fact, paid in exchange for the waiver and release or a single payee check or joint payee check is given in exchange for the waiver and release, the waiver and release shall be null, void, and unenforceable unless it is in substantially the following form: CONDITIONAL WAIVER AND RELEASE ON FINAL PAYMENT NOTICE: THIS DOCUMENT WAIVES THE CLAIMANT'S LIEN, STOP PAYMENT NOTICE, AND PAYMENT BOND RIGHTS EFFECTIVE ON RECEIPT OF PAYMENT. A PERSON SHOULD NOT RELY ON THIS DOCUMENT UNLESS SATISFIED THAT THE CLAIMANT HAS RECEIVED PAYMENT. Identifying Information Name of Claimant:_______________________________ Name of Customer:_______________________________ Job Location:___________________________________ Owner:__________________________________________ Conditional Waiver and Release This document waives and releases lien, stop payment notice, and payment bond rights the claimant has for labor and service provided, and equipment and material delivered, to the customer on this job. Rights based upon labor or service provided, or equipment or material delivered, pursuant to a written change order that has been fully executed by the parties prior to the date that this document is signed by the claimant, are waived and released by this document, unless listed as an Exception below. This document is effective only on the claimant's receipt of payment from the financial institution on which the following check is drawn: Maker of Check:_________________________________ Amount of Check: $______________________________ Check Payable to:_______________________________ Exceptions This document does not affect any of the following: Disputed claims for extras in the amount of: $ _______________________ Signature Claimant's Signature:___________________________ Claimant's Title:_______________________________ Date of Signature:______________________________ 8138. If the claimant is required to execute a waiver and release in exchange for, or in order to induce payment of, a final payment and the claimant asserts in the waiver that the claimant has, in fact, been paid the final payment, the waiver and release shall be null, void, and unenforceable unless it is in substantially the following form, with the text of the "Notice to Claimant" in at least as large a type as the largest type otherwise in the form: UNCONDITIONAL WAIVER AND RELEASE ON FINAL PAYMENT NOTICE TO CLAIMANT: THIS DOCUMENT WAIVES AND RELEASES LIEN, STOP PAYMENT NOTICE, AND PAYMENT BOND RIGHTS UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS. THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT BEEN PAID. IF YOU HAVE NOT BEEN PAID, USE A CONDITIONAL WAIVER AND RELEASE FORM. Identifying Information Name of Claimant:_______________________________ Name of Customer:_______________________________ Job Location:___________________________________ Owner:__________________________________________ Unconditional Waiver and Release This document waives and releases lien, stop payment notice, and payment bond rights the claimant has for all labor and service provided, and equipment and material delivered, to the customer on this job. Rights based upon labor or service provided, or equipment or material delivered, pursuant to a written change order that has been fully executed by the parties prior to the date that this document is signed by the claimant, are waived and released by this document, unless listed as an Exception below. The claimant has been paid in full. Exceptions This document does not affect the following: Disputed claims for extras in the amount of: $ ________________ Signature Claimant's Signature:___________________________ Claimant's Title:_______________________________ Date of Signature:______________________________ CHAPTER 4. BONDS 8150. The Bond and Undertaking Law (Chapter 2 (commencing with Section 995.010) of Title 14 of Part 2 of the Code of Civil Procedure) applies to a bond given under this part, except to the extent this part prescribes a different rule or is inconsistent. 8152. None of the following releases a surety from liability on a bond given under this part: (a) A change, alteration, or modification to a contract, plan, specification, or agreement for a work of improvement or for work provided for a work of improvement. (b) A change or modification to the terms of payment or an extension of the time for payment for a work of improvement. (c) A rescission or attempted rescission of a contract, agreement, or bond. (d) A condition precedent or subsequent in the bond purporting to limit the right of recovery of a claimant otherwise entitled to recover pursuant to a contract, agreement, or bond. (e) In the case of a bond given for the benefit of claimants, the fraud of a person other than the claimant seeking to recover on the bond. 8154. (a) A bond given under this part shall be construed most strongly against the surety and in favor of all persons for whose benefit the bond is given. (b) A surety is not released from liability to those for whose benefit the bond has been given by reason of a breach of the direct contract or on the part of any obligee named in the bond. (c) Except as otherwise provided by statute, the sole conditions of recovery on the bond are that the claimant is a person described in Article 1 (commencing with Section 8400) of Chapter 4 of Title 2, or in Section 9100, and has not been paid the full amount of the claim. TITLE 2. PRIVATE WORKS OF IMPROVEMENT CHAPTER 1. GENERAL PROVISIONS Article 1. Application of Title 8160. This title applies to a work of improvement that is not governed by Title 3 (commencing with Section 9000) of this part. Article 2. Construction Documents 8170. (a) A written direct contract shall provide a space for the owner to enter the following information: (1) The owner's name, address, and place of business, if any. (2) The name and address of the construction lender, if any. This paragraph does not apply to a home improvement contract or swimming pool contract subject to Article 10 (commencing with Section 7150) of Chapter 9 of Division 3 of the Business and Professions Code. (b) A written contract entered into between a direct contractor and subcontractor, or between subcontractors, shall provide a space for the name and address of the owner, direct contractor, and construction lender, if any. 8172. (a) A public entity that issues building permits shall, in its application form for a building permit, provide space and a designation for the applicant to enter the name, branch designation, if any, and address of the construction lender and shall keep the information on file open for public inspection during the regular business hours of the public entity. (b) If there is no known construction lender, the applicant shall note that fact in the designated space. (c) Failure of the applicant to indicate the name and address of the construction lender on the application does not relieve a person required to give the construction lender preliminary notice from that duty. 8174. (a) A mortgage, deed of trust, or other instrument securing a loan, any of the proceeds of which may be used for a work of improvement, shall bear the designation "Construction Trust Deed" prominently on its face and shall state all of the following: (1) The name and address of the construction lender. (2) The name and address of the owner of the real property described in the instrument. (3) A legal description of the real property that secures the loan and, if known, the street address of the property. (b) Failure to comply with subdivision (a) does not affect the validity of the mortgage, deed of trust, or other instrument. (c) Failure to comply with subdivision (a) does not relieve a person required to give preliminary notice from that duty. (d) The county recorder of the county in which the instrument is recorded shall indicate in the general index of the official records of the county that the instrument secures a construction loan. Article 3. Completion 8180. (a) For the purpose of this title, completion of a work of improvement occurs upon the occurrence of any of the following events: (1) Actual completion of the work of improvement. (2) Occupation or use by the owner accompanied by cessation of labor. (3) Cessation of labor for a continuous period of 60 days. (4) Recordation of a notice of cessation after cessation of labor for a continuous period of 30 days. (b) Notwithstanding subdivision (a), if a work of improvement is subject to acceptance by a public entity, completion occurs on acceptance. 8182. (a) An owner may record a notice of completion on or within 15 days after the date of completion of a work of improvement. (b) The notice of completion shall be signed and verified by the owner. (c) The notice shall comply with the requirements of Chapter 2 (commencing with Section 8100) of Title 1, and shall also include all of the following information: (1) If the notice is given only of completion of a contract for a particular portion of the work of improvement as provided in Section 8186, the name of the direct contractor under that contract and a general statement of the work provided pursuant to the contract. (2) If signed by the owner's successor in interest, the name and address of the successor's transferor. (3) The nature of the interest or estate of the owner. (4) The date of completion. An erroneous statement of the date of completion does not affect the effectiveness of the notice if the true date of completion is 15 days or less before the date of recordation of the notice. (d) A notice of completion that does not comply with the provisions of this section is not effective. (e) For the purpose of this section, "owner" means the owner who causes a building, improvement, or structure to be constructed, altered, or repaired, or that person's successor in interest at the date a notice of completion is recorded, whether the interest or estate of the owner be in fee, as vendee under a contract of purchase, as lessee, or other interest or estate less than the fee. Where the interest or estate is held by two or more persons as joint tenants or tenants in common, any one or more of the cotenants may be deemed to be the "owner" within the meaning of this section. 8184. A notice of completion in otherwise proper form, verified and containing the information required by this title, shall be accepted by the recorder for recording and is deemed duly recorded without acknowledgment. 8186. If a work of improvement is made pursuant to two or more direct contracts, each covering a portion of the work of improvement: (a) The owner may record a notice of completion of a direct contract for a portion of the work of improvement. On recordation of the notice of completion, for the purpose of Sections 8412 and 8414, a direct contractor is deemed to have completed the contract for which the notice of completion is recorded and a claimant other than a direct contractor is deemed to have ceased providing work. (b) If the owner does not record a notice of completion under this section, the period for recording a claim of lien is that provided in Sections 8412 and 8414. 8188. (a) An owner may record a notice of cessation if there has been a continuous cessation of labor on a work of improvement for at least 30 days prior to the recordation that continues through the date of the recordation. (b) The notice shall be signed and verified by the owner. (c) The notice shall comply with the requirements of Chapter 2 (commencing with Section 8100) of Title 1, and shall also include all of the following information: (1) The date on or about which labor ceased. (2) A statement that the cessation has continued until the recordation of the notice. (d) For the purpose of this section, "owner" means the owner who causes a building, improvement, or structure to be constructed, altered, or repaired, or that person's successor in interest at the date a notice of cessation is recorded, whether the interest or estate of the owner be in fee, as vendee under a contract of purchase, as lessee, or other interest or estate less than the fee. Where the interest or estate is held by two or more persons as joint tenants or tenants in common, any one or more of the cotenants may be deemed to be the "owner" within the meaning of this section. 8190. (a) An owner that records a notice of completion or cessation shall, within 10 days of the date the notice of completion or cessation is filed for record, give a copy of the notice to all of the following persons: (1) A direct contractor. (2) A claimant that has given the owner preliminary notice. (b) The copy of the notice shall be given in compliance with the requirements of Chapter 2 (commencing with Section 8100) of Title 1. (c) If the owner fails to give notice to a person as required by subdivision (a), the notice is ineffective to shorten the time within which that person may record a claim of lien under Sections 8412 and 1. 8414. The ineffectiveness of the notice is the sole liability of the 2. owner for failure to give notice to a person under subdivision (a). (d) For the purpose of this section, "owner" means a person who has an interest in real property, or the person's successor in interest on the date a notice of completion or notice of cessation is recorded, who causes a building, improvement, or structure, to be constructed, altered, or repaired on the property. If the property is owned by two or more persons as joint tenants or tenants in common, any one or more of the cotenants may be deemed to be the "owner" within the meaning of this section. However, this section does not apply to any of the following owners: (1) A person that occupies the real property as a personal residence, if the dwelling contains four or fewer residential units. (2) A person that has a security interest in the property. (3) A person that obtains an interest in the property pursuant to a transfer described in subdivision (b), (c), or (d) of Section 1102.2. CHAPTER 2. PRELIMINARY NOTICE 8200. (a) Except as otherwise provided by statute, before recording a lien claim, giving a stop payment notice, or asserting a claim against a payment bond, a claimant shall give preliminary notice to the following persons: (1) The owner or reputed owner. (2) The direct contractor or reputed direct contractor to which the claimant provides work, either directly or through one or more subcontractors. (3) The construction lender or reputed construction lender, if any. (b) The notice shall comply with the requirements of Chapter 2 (commencing with Section 8100) of Title 1. (c) Compliance with this section is a necessary prerequisite to the validity of a lien claim or stop payment notice under this title. (d) Compliance with this section or with Section 8612 is a necessary prerequisite to the validity of a claim against a payment bond under this title. (e) Notwithstanding the foregoing subdivisions: (1) A laborer is not required to give preliminary notice. (2) A claimant with a direct contractual relationship with an owner or reputed owner is required to give preliminary notice only to the construction lender or reputed construction lender, if any. 8202. (a) The preliminary notice shall comply with the requirements of Section 8102, and shall also include: (1) A general description of the work to be provided. (2) An estimate of the total price of the work provided and to be provided. (3) The following statement in boldface type: NOTICE TO PROPERTY OWNER EVEN THOUGH YOU HAVE PAID YOUR CONTRACTOR IN FULL, if the person or firm that has given you this notice is not paid in full for labor, service, equipment, or material provided or to be provided to your construction project, a lien may be placed on your property. Foreclosure of the lien may lead to loss of all or part of your property. You may wish to protect yourself against this by (1) requiring your contractor to provide a signed release by the person or firm that has given you this notice before making payment to your contractor, or (2) any other method that is appropriate under the circumstances. This notice is required by law to be served by the undersigned as a statement of your legal rights. This notice is not intended to reflect upon the financial condition of the contractor or the person employed by you on the construction project. If you record a notice of cessation or completion of your construction project, you must within 10 days after recording, send a copy of the notice of completion to your contractor and the person or firm that has given you this notice. The notice must be sent by registered or certified mail. Failure to send the notice will extend the deadline to record a claim of lien. You are not required to send the notice if you are a residential homeowner of a dwelling containing four or fewer units. (b) If preliminary notice is given by a subcontractor that has not paid all compensation due to a laborer, the notice shall include the name and address of the laborer and any person or entity described in subdivision (b) of Section 8024 to which payments are due. (c) If an invoice for material or certified payroll contains the information required by this section and Section 8102, a copy of the invoice or payroll, given in compliance with the requirements of Chapter 2 (commencing with Section 8100) of Title 1, is sufficient. 8204. (a) A preliminary notice shall be given not later than 20 days after the claimant has first furnished work on the work of improvement. If work has been provided by a claimant who did not give a preliminary notice, that claimant shall not be precluded from giving a preliminary notice at any time thereafter. The claimant shall, however, be entitled to record a lien, give a stop payment notice, and assert a claim against a payment bond only for work performed within 20 days prior to the service of the preliminary notice, and at any time thereafter. (b) A design professional who has furnished services for the design of the work of improvement and who gives a preliminary notice not later than 20 days after the work of improvement has commenced shall be deemed to have complied with Section 8200 with respect to the design services furnished, or to be furnished. 8206. (a) Except as provided in subdivision (b), a claimant need give only one preliminary notice to each person to which notice must be given under this chapter with respect to all work provided by the claimant for a work of improvement. (b) If a claimant provides work pursuant to contracts with more than one subcontractor, the claimant shall give a separate preliminary notice with respect to work provided pursuant to each contract. (c) A preliminary notice that contains a general description of work provided by the claimant through the date of the notice also covers work provided by the claimant after the date of the notice whether or not they are within the scope of the general description contained in the notice. 8208. A direct contractor shall make available to any person seeking to give preliminary notice the following information: (a) The name and address of the owner. (b) The name and address of the construction lender, if any. 8210. If one or more construction loans are obtained after commencement of a work of improvement, the owner shall give notice of the name and address of the construction lender or lenders to each person that has given the owner preliminary notice. 8212. An agreement made or entered into by an owner whereby the owner agrees to waive the rights conferred on the owner by this chapter is void and unenforceable. 8214. (a) Each person who has served a preliminary notice may file the preliminary notice with the county recorder. A preliminary notice filed pursuant to this section shall comply with the requirements of Section 8102. (b) Upon the acceptance for recording of a notice of completion or notice of cessation the county recorder shall mail to those persons who have filed a preliminary notice, notification that a notice of completion or notice of cessation has been recorded on the property, and shall affix the date that the notice of completion or notice of cessation was recorded with the county recorder. The notification given by the county recorder under this section is not governed by the requirements of Chapter 2 (commencing with Section 8100) of Title 1. (c) The failure of the county recorder to mail the notification to the person who filed a preliminary notice, or the failure of those persons to receive the notification or to receive complete notification, shall not affect the period within which a claim of lien is required to be recorded. However, the county recorder shall make a good faith effort to mail notification to those persons who have filed the preliminary notice under this section and to do so within five days after the recording of a notice of completion or notice of cessation. (d) The county recorder may cause to be destroyed all documents filed pursuant to this section, two years after the date of filing. (e) The preliminary notice that a person may file pursuant to this section is for the limited purpose of facilitating the mailing of notice by the county recorder of recorded notices of completion and notices of cessation. The notice that is filed is not a recordable document and shall not be entered into those official records of the county which by law impart constructive notice. Notwithstanding any other provision of law, the index maintained by the recorder of filed preliminary notices shall be separate and distinct from those indexes maintained by the county recorder of those official records of the county which by law impart constructive notice. The filing of a preliminary notice with the county recorder does not give rise to any actual or constructive notice with respect to any party of the existence or contents of a filed preliminary notice nor to any duty of inquiry on the part of any party as to the existence or contents of that notice. 8216. If the contract of any subcontractor on a particular work of improvement provides for payment to the subcontractor of more than four hundred dollars ($400), the failure of that subcontractor, licensed under the Contractors' State License Law (Chapter 9 (commencing with Section 7000) of Division 3 of the Business and Professions Code), to give the notice provided for in this chapter, constitutes grounds for disciplinary action under the Contractors' State License Law. CHAPTER 3. DESIGN PROFESSIONALS LIEN 8300. For purposes of this chapter, a "design professional" is a person described in Section 8014 who provides services pursuant to a written contract with a landowner for the design, engineering, or planning of a work of improvement. 8302. (a) A design professional has, from the date of recordation of a claim of lien under this chapter, a lien on the site notwithstanding the absence of commencement of the planned work of improvement, if the landowner who contracted for the design professional's services is also the owner of the site at the time of recordation of the claim of lien. (b) The lien of the design professional is for the amount of the design professional's fee for services provided under the contract or the reasonable value of those services, whichever is less. The amount of the lien is reduced by the amount of any deposit or prior payment under the contract. (c) A design professional may not record a claim of lien, and a lien may not be created, under this chapter unless a building permit or other governmental approval in furtherance of the work of improvement has been obtained in connection with or utilizing the services provided by the design professional. 8304. A design professional is not entitled to a lien under this chapter unless all of the following conditions are satisfied: (a) The work of improvement for which the design professional provided services has not commenced. (b) The landowner defaults in a payment required under the contract or refuses to pay the demand of the design professional made under the contract. (c) Not less than 10 days before recording a claim of lien, the design professional gives the landowner notice making a demand for payment, and stating that a default has occurred under the contract and the amount of the default. (d) The design professional records a claim of lien. The claim of lien shall include all of the following information: (1) The name of the design professional. (2) The amount of the claim. (3) The current owner of record of the site. (4) A legal description of the site. (5) Identification of the building permit or other governmental approval for the work of improvement. 8306. (a) On recordation of the claim of lien, a lien is created in favor of the named design professional. (b) The lien automatically expires and is null and void and of no further force or effect on the occurrence of either of the following events: (1) The commencement of the work of improvement for which the design professional provided services. (2) The expiration of 90 days after recording the claim of lien, unless the design professional commences an action to enforce the lien within that time. (c) If the landowner partially or fully satisfies the lien, the design professional shall execute and record a document that evidences a partial or full satisfaction and release of the lien, as applicable. 8308. (a) Except as provided in subdivision (b), no provision of this part applies to a lien created under this chapter. (b) The following provisions of this part apply to a lien created under this chapter: (1) This chapter. (2) Article 1 (commencing with Section 8000) of Chapter 1 of Title 1. (3) Section 8424. (4) Article 6 (commencing with Section 8460) of Chapter 4. (5) Article 7 (commencing with Section 8480) of Chapter 4. (6) Article 8 (commencing with Section 8490) of Chapter 4. 8310. This chapter does not affect the ability of a design professional to obtain a lien for a work of improvement under Section 8400. 8312. A design professional shall record a claim of lien under this chapter no later than 90 days after the design professional knows or has reason to know that the work of improvement will not be commenced. 8314. The creation of a lien under this chapter does not affect the ability of the design professional to pursue other remedies. 8316. (a) No lien created under this chapter affects or takes priority over the interest of record of a purchaser, lessee, or encumbrancer, if the interest of the purchaser, lessee, or encumbrancer in the real property was duly recorded before recordation of the claim of lien. (b) No lien created under this chapter affects or takes priority over an encumbrance of a construction lender that funds the loan for the work of improvement for which the design professional provided services. 8318. A design professional may not obtain a lien under this chapter for services provided for a work of improvement relating to a single-family, owner-occupied residence for which the expected construction cost is less than one hundred thousand dollars ($100,000). 8319. (a) A design professional may convert a recorded design professional lien to a mechanics lien if all of the following requirements are met: (1) The design professional lien expires pursuant to paragraph (1) of subdivision (b) of Section 8306. (2) The design professional lien remains fully or partially unpaid. (3) Within 30 days of the expiration of the design professional lien pursuant to paragraph (1) of subdivision (b) of Section 8306, the design professional records a mechanics lien for the amount of the unpaid design professional lien. (4) The recorded mechanics lien states that it is a converted design professional lien but shall be recorded and enforced as a mechanics lien, except the design professional need not provide a preliminary notice to enforce this mechanics lien. This mechanics lien shall be effective as of the date of recordation of this mechanics lien and shall be given priority pursuant to the provisions of Section 8450. (b) This section shall not apply if a design professional lien expires pursuant to paragraph (2) of subdivision (b) of Section 8306. CHAPTER 4. MECHANICS LIEN Article 1. Who is Entitled to Lien 8400. A person that provides work authorized for a work of improvement, including, but not limited to, the following persons, has a lien right under this chapter: (a) Direct contractor. (b) Subcontractor. (c) Material supplier. (d) Equipment lessor. (e) Laborer. (f) Design professional. 8402. A person that provides work authorized for a site improvement has a lien right under this chapter. 8404. Work is authorized for a work of improvement or for a site improvement in any of the following circumstances: (a) It is provided at the request of or agreed to by the owner. (b) It is provided or authorized by a direct contractor, subcontractor, architect, project manager, or other person having charge of all or part of the work of improvement or site improvement. Article 2. Conditions to Enforcing a Lien 8410. A claimant may enforce a lien only if the claimant has given preliminary notice to the extent required by Chapter 2 (commencing with Section 8200) and made proof of notice. 8412. A direct contractor may not enforce a lien unless the contractor records a claim of lien after the contractor completes the direct contract, and before the earlier of the following times: (a) Ninety days after completion of the work of improvement. (b) Sixty days after the owner records a notice of completion or cessation. 8414. A claimant other than a direct contractor may not enforce a lien unless the claimant records a claim of lien within the following times: (a) After the claimant ceases to provide work. (b) Before the earlier of the following times: (1) Ninety days after completion of the work of improvement. (2) Thirty days after the owner records a notice of completion or cessation. 8416. (a) A claim of mechanics lien shall be a written statement, signed and verified by the claimant, containing all of the following: (1) A statement of the claimant's demand after deducting all just credits and offsets. (2) The name of the owner or reputed owner, if known. (3) A general statement of the kind of work furnished by the claimant. (4) The name of the person by whom the claimant was employed or to whom the claimant furnished work. (5) A description of the site sufficient for identification. (6) The claimant's address. (7) A proof of service affidavit completed and signed by the person serving a copy of the claim of mechanics lien pursuant to subdivision (c). The affidavit shall show the date, place, and manner of service, and facts showing that the service was made in accordance with this section. The affidavit shall show the name and address of the person or persons upon whom the copy of the claim of mechanics lien was served, and, if appropriate, the title or capacity in which he or she was served. (8) The following statement, printed in at least 10-point boldface type. The letters of the last sentence shall be printed in uppercase type, excepting the Internet Web site address of the Contractors' State License Board, which shall be printed in lowercase type: ""NOTICE OF MECHANICS LIEN ATTENTION! Upon the recording of the enclosed MECHANICS LIEN with the county recorder's office of the county where the property is located, your property is subject to the filing of a legal action seeking a court-ordered foreclosure sale of the real property on which the lien has been recorded. That legal action must be filed with the court no later than 90 days after the date the mechanics lien is recorded. The party identified in the enclosed mechanics lien may have provided labor or materials for improvements to your property and may not have been paid for these items. You are receiving this notice because it is a required step in filing a mechanics lien foreclosure action against your property. The foreclosure action will seek a sale of your property in order to pay for unpaid labor, materials, or improvements provided to your property. This may affect your ability to borrow against, refinance, or sell the property until the mechanics lien is released. BECAUSE THE LIEN AFFECTS YOUR PROPERTY, YOU MAY WISH TO SPEAK WITH YOUR CONTRACTOR IMMEDIATELY, OR CONTACT AN ATTORNEY, OR FOR MORE INFORMATION ON MECHANICS LIENS GO TO THE CONTRACTORS' STATE LICENSE BOARD WEB SITE AT www.cslb.ca.gov.'' (b) A claim of mechanics lien in otherwise proper form, verified and containing the information required in subdivision (a), shall be accepted by the recorder for recording and shall be deemed duly recorded without acknowledgment. (c) A copy of the claim of mechanics lien, which includes the Notice of Mechanics Lien required by paragraph (8) of subdivision (a), shall be served on the owner or reputed owner. Service shall be made as follows: (1) For an owner or reputed owner to be notified who resides in or outside this state, by registered mail, certified mail, or first-class mail, evidenced by a certificate of mailing, postage prepaid, addressed to the owner or reputed owner at the owner's or reputed owner's residence or place of business address or at the address shown by the building permit on file with the authority issuing a building permit for the work, or as otherwise provided in Section 8174. (2) If the owner or reputed owner cannot be served by this method, then the copy of the claim of mechanics lien may be given by registered mail, certified mail, or first-class mail, evidenced by a certificate of mailing, postage prepaid, addressed to the construction lender or to the original contractor. (d) Service of the copy of the claim of mechanics lien by registered mail, certified mail, or first-class mail, evidenced by a certificate of mailing, postage prepaid, is complete at the time of the deposit of that first-class, certified, or registered mail. (e) Failure to serve the copy of the claim of mechanics lien as prescribed by this section, including the Notice of Mechanics Lien required by paragraph (8) of subdivision (a), shall cause the claim of mechanics lien to be unenforceable as a matter of law. 8422. (a) Except as provided in subdivisions (b) and (c), erroneous information contained in a claim of lien relating to the claimant's demand, credits and offsets deducted, the work provided, or the description of the site, does not invalidate the claim of lien. (b) Erroneous information contained in a claim of lien relating to the claimant's demand, credits and offsets deducted, or the work provided, invalidates the claim of lien if the court determines either of the following: (1) The claim of lien was made with intent to defraud. (2) An innocent third party, without notice, actual or constructive, became the bona fide owner of the property after recordation of the claim of lien, and the claim of lien was so deficient that it did not put the party on further inquiry in any manner. (c) Any person who shall willfully include in a claim of lien labor, services, equipment, or materials not furnished for the property described in the claim, shall thereby forfeit the person's lien. 8424. (a) An owner of real property or an owner of any interest in real property subject to a recorded claim of lien, or a direct contractor or subcontractor affected by the claim of lien, that disputes the correctness or validity of the claim may obtain release of the real property from the claim of lien by recording a lien release bond. The principal on the bond may be the owner of the property, the direct contractor, or the subcontractor. (b) The bond shall be conditioned on payment of any judgment and costs the claimant recovers on the lien. The bond shall be in an amount equal to 125 percent of the amount of the claim of lien or 125 percent of the amount allocated in the claim of lien to the real property to be released. The bond shall be executed by an admitted surety insurer. (c) The bond may be recorded either before or after commencement of an action to enforce the lien. On recordation of the bond, the real property is released from the claim of lien and from any action to enforce the lien. (d) A person that obtains and records a lien release bond shall give notice to the claimant. The notice shall comply with the requirements of Chapter 2 (commencing with Section 8100) of Title 1 and shall include a copy of the bond. Failure to give the notice required by this section does not affect the validity of the bond, but the statute of limitations for an action on the bond is tolled until notice is given. The claimant shall commence an action on the bond within six months after notice is given. Article 3. Amount of Lien 8430. (a) The lien is a direct lien for the lesser of the following amounts: (1) The reasonable value of the work provided by the claimant. (2) The price agreed to by the claimant and the person that contracted for the work. (b) The lien is not limited in amount by the contract price foSorry, this device is not supported
Please open this page on your desktop computer.
