US Legal Forms
Maine Site Work Contract for Contractor

Maine Site Work Contract for Contractor

Name: Maine Site Work Contract for Contractor
Brand: US Legal Forms
Price: 59.00 USD
Rating: 4.61 (262 reviews)

Category:

Maine Construction - Contractors - Site Work

State:

Maine

Control #:

ME-00462-23

Format:

Instant download

Upgrade to a Package! Site Work Contractor Value Pack. Essential Forms. Go to Package

Description

This form is designed for use between Site Work Contractors and Property Owners and may be executed with either a cost plus or fixed fee payment arrangement. This contract addresses such matters as change orders, work site information, warranty and insurance. This form was specifically drafted to comply with the laws of the State of Maine.

View A11 Plaintiff's Memorandum in Support of Motion for Judgment By Default Against Defendant

View this form

View A10 Declaration of Counsel in Support of Motion for Judgment by Default

View this form

View A09 Plaintiff's Motion for Judgment by Default Against Defendant

View this form

View A08 Order of Default Against Defendant

View this form

View A06 Plaintiff's Application for Order of Default Against Defendant

View this form

How to fill out Maine Site Work Contract For Contractor?

You are welcome to the greatest legal files library, US Legal Forms. Right here you will find any template such as Maine Site Work Contract for Contractor forms and save them (as many of them as you want/need). Get ready official documents with a few hours, rather than days or even weeks, without spending an arm and a leg on an attorney. Get your state-specific sample in a few clicks and feel assured with the knowledge that it was drafted by our accredited legal professionals.

If you’re already a subscribed customer, just log in to your account and click Download next to the Maine Site Work Contract for Contractor you require. Because US Legal Forms is online solution, you’ll always get access to your saved files, no matter what device you’re using. Locate them inside the My Forms tab.

If you don't have an account yet, just what are you awaiting? Check our guidelines below to start:

If this is a state-specific document, check its validity in your state.
View the description (if accessible) to learn if it’s the correct example.
See much more content with the Preview feature.
If the example matches your requirements, just click Buy Now.
To make an account, select a pricing plan.
Use a card or PayPal account to subscribe.
Save the document in the format you want (Word or PDF).
Print the file and fill it with your/your business’s details.

After you’ve filled out the Maine Site Work Contract for Contractor, send away it to your lawyer for confirmation. It’s an additional step but a necessary one for making sure you’re completely covered. Sign up for US Legal Forms now and access a mass amount of reusable samples.

Form Rating

4.61

Satisfied(262)

Form popularity

FAQ

Contract Types Overview. Express and Implied Contracts. Unilateral and Bilateral Contracts. Unconscionable Contracts. Adhesion Contracts. Aleatory Contracts. Option Contracts. Fixed Price Contracts.

Name of contractor and contact information. Name of homeowner and contact information. Describe property in legal terms. List attachments to the contract. The cost. Failure of homeowner to obtain financing. Description of the work and the completion date. Right to stop the project.

Both parties should sign the contract, and both should be bound by the terms and conditions spelled out in the agreement. In general that means the contractor will be obliged to provide specified materials and to perform certain services for you. In turn, you will be required to pay for those goods and that labor.

If you run a small business that hires 1099 contractors, also known as independent contractors, it is vital that you have them sign an independent contractor contract. This is because there is a significant gray area between who is classified as an independent contractor and who is classified as an employee.

Identifying/Contact Information. Title and Description of the Project. Projected Timeline and Completion Date. Cost Estimate and Payment Schedule. Stop Work Clause and Stop Payment Clause. Act of God Clause. Change Order Agreement. Warranty.

Unlike other states, Maine doesn't require general contractors to be licensedonly plumbers, electricians, and contractors who do specialty work. Check out the full list of who needs to be licensed here. Instead, general contractors need to apply for Maine business licenses.

Begin with the Date and the Address of the Other Party. Start with the Basic Details of the Planned Work. Include Special Stipulations. State Whether There Will be a Further Agreement. Create an Area for Signatures. Sign and Date the Contract Letter.

Homeowners who enter into contracts with contractors to improve, remodel or repair their homes almost always have a right to cancel the contract, without any penalty or obligation, within three business days after signing the contract.

#1: Review Your Bid. #2: Review Complete Plans. #3: Review All Specifications. #4: Visit the Job Site. #5: Review the Job Schedule. #6: Complete a Project Checklist. #7: Verify Project Funding. #8: Read Complete Contract.

Maine Site Work Contract for Contractor

Description

Related forms

How to fill out Maine Site Work Contract For Contractor?

Show more info

Form Rating

Form popularity

FAQ

What are the 4 types of contracts?

What should be included in a contractor's contract?

Do you sign a contract with a contractor?

Should I sign an independent contractor agreement?

How do I write a contract for a general contractor?

Does Maine require contractors to be licensed?

How do you write a contract letter?

Can you cancel a contract with a contractor?

How do you sign a good construction contract?

Trusted and secure by over 3 million people of the world’s leading companies