Georgia Agreement between Owner and Construction Manager for Services in Overseeing a Construction Project

• Category: Construction - Contractors
• State: Multi-State
• Control #: US-0056BG
• Format: Word; Rich Text

Description

A Construction Management Agreement is a contract drafted and signed by a construction foreman and the property owner. It allows each to establish roles and responsibilities, deadlines, wages and the project specifics. A Georgia Agreement between Owner and Construction Manager for Services in Overseeing a Construction Project is a legally binding document that outlines the terms and conditions of the relationship between the owner of a construction project and the construction manager. This agreement is specific to construction projects located within the state of Georgia. The agreement typically includes various important clauses and provisions that address the responsibilities and duties of both parties involved. Some key components mentioned in the agreement are as follows: 1. Parties involved: The agreement should clearly identify the owner and the construction manager. It should also include their contact details and legal names. 2. Scope of work: This section outlines the specific services the construction manager will provide in overseeing the construction project. It includes tasks such as project planning, scheduling, coordination, and approval of design changes. It may also involve supervising subcontractors, ensuring compliance with regulatory requirements, and managing the budget. 3. Duration: The agreement states the start date and expected completion date of the project, as well as any milestones or deadlines for crucial phases of construction. 4. Compensation: The agreement outlines the payment terms, which may include a lump-sum fee, a percentage of the project cost, or a predetermined hourly rate. It should also specify the schedule and method of payment. 5. Insurance and liability: This section discusses the insurance requirements for the construction manager, including liability coverage and workers' compensation insurance. It should also include provisions regarding indemnification and hold harmless clauses. 6. Change orders: The agreement details the process for handling any changes or modifications to the scope of work during the construction process. It may require written approval from the owner before implementing any changes. 7. Dispute resolution: This section outlines the procedure for resolving disputes or disagreements that may arise during the course of the project, including mediation, arbitration, or litigation. Different types or variations of the Georgia Agreement between Owner and Construction Manager for Services in Overseeing a Construction Project may exist based on the complexity of the project or specific requirements of the parties involved. Some variations could include agreements tailored for residential construction projects, commercial projects, government projects, or large-scale developments. It is essential to ensure that the agreement is specifically designed to meet the unique needs and circumstances of the project at hand.

A Georgia Agreement between Owner and Construction Manager for Services in Overseeing a Construction Project is a legally binding document that outlines the terms and conditions of the relationship between the owner of a construction project and the construction manager. This agreement is specific to construction projects located within the state of Georgia. The agreement typically includes various important clauses and provisions that address the responsibilities and duties of both parties involved. Some key components mentioned in the agreement are as follows: 1. Parties involved: The agreement should clearly identify the owner and the construction manager. It should also include their contact details and legal names. 2. Scope of work: This section outlines the specific services the construction manager will provide in overseeing the construction project. It includes tasks such as project planning, scheduling, coordination, and approval of design changes. It may also involve supervising subcontractors, ensuring compliance with regulatory requirements, and managing the budget. 3. Duration: The agreement states the start date and expected completion date of the project, as well as any milestones or deadlines for crucial phases of construction. 4. Compensation: The agreement outlines the payment terms, which may include a lump-sum fee, a percentage of the project cost, or a predetermined hourly rate. It should also specify the schedule and method of payment. 5. Insurance and liability: This section discusses the insurance requirements for the construction manager, including liability coverage and workers' compensation insurance. It should also include provisions regarding indemnification and hold harmless clauses. 6. Change orders: The agreement details the process for handling any changes or modifications to the scope of work during the construction process. It may require written approval from the owner before implementing any changes. 7. Dispute resolution: This section outlines the procedure for resolving disputes or disagreements that may arise during the course of the project, including mediation, arbitration, or litigation. Different types or variations of the Georgia Agreement between Owner and Construction Manager for Services in Overseeing a Construction Project may exist based on the complexity of the project or specific requirements of the parties involved. Some variations could include agreements tailored for residential construction projects, commercial projects, government projects, or large-scale developments. It is essential to ensure that the agreement is specifically designed to meet the unique needs and circumstances of the project at hand.