Maryland Agreement between Owner and Construction Manager for Services in Overseeing a Construction Project

• Category: Construction - Contractors
• State: Multi-State
• Control #: US-0056BG
• Format: Word; Rich Text

Description

A Construction Management Agreement is a contract drafted and signed by a construction foreman and the property owner. It allows each to establish roles and responsibilities, deadlines, wages and the project specifics. Maryland Agreement between Owner and Construction Manager for Services in Overseeing a Construction Project is a legally binding contract that establishes the roles, responsibilities, and expectations for both parties involved in the management and execution of a construction project in the state of Maryland. This agreement ensures clarity and effective communication throughout the construction process. The primary purpose of this agreement is to define the scope of work and outline the services provided by the Construction Manager (CM) in overseeing the construction project on behalf of the Owner. It establishes the contractual and financial obligations of both parties, helping to minimize disputes and ensure a successful delivery of the project. Some key provisions included in a Maryland Agreement between Owner and Construction Manager for Services may include: 1. Project Description: This section identifies the project's location, purpose, and overall objectives. It provides a detailed description of the scope of work, including any specific requirements, permits, or regulations that may be applicable to the project. 2. Roles and Responsibilities: This portion of the agreement clearly defines the roles and responsibilities of the Owner and the Construction Manager. It outlines the specific duties and obligations that each party is expected to fulfill throughout the duration of the construction project. 3. Payment Terms: This section discusses the financial aspects of the agreement, including the CM's compensation structure, payment milestones, and any additional costs for changes or modifications requested by the Owner. It may also highlight the consequences of late payments or non-payment. 4. Project Schedule and Milestones: This section establishes the overall project timeline, including expected start and completion dates, as well as specific milestones or deadlines that need to be met. It provides a framework for the CM to manage the project efficiently and keep it on track. 5. Change Orders: This clause addresses any changes or modifications to the original scope of work and the process for approving and implementing such changes. It ensures that any alterations are properly documented, agreed upon, and appropriately compensated. 6. Dispute Resolution: This section outlines the procedure for resolving any disputes or conflicts that may arise during the course of the construction project. It may include a requirement for mediation, arbitration, or litigation, depending on the preferences of the parties involved. Different types of Maryland Agreements between Owner and Construction Manager for Services may exist depending on various factors such as the size and complexity of the project, the delivery method chosen (e.g., design-bid-build, design-build, construction manager at risk), and the specific needs and preferences of the parties involved. Some specialized agreements may also address unique situations or project requirements, such as Maryland Agreement between Owner and Construction Manager for Services in Federal Government Projects, Maryland Agreement between Owner and Construction Manager for Services in Public Infrastructure Projects, or Maryland Agreement between Owner and Construction Manager for Services in Residential Construction Projects. In conclusion, a Maryland Agreement between Owner and Construction Manager for Services in Overseeing a Construction Project is a crucial legal document that outlines the expectations, responsibilities, and obligations of both the Owner and the Construction Manager. It ensures effective project management, clear communication, and successful project execution.

Maryland Agreement between Owner and Construction Manager for Services in Overseeing a Construction Project is a legally binding contract that establishes the roles, responsibilities, and expectations for both parties involved in the management and execution of a construction project in the state of Maryland. This agreement ensures clarity and effective communication throughout the construction process. The primary purpose of this agreement is to define the scope of work and outline the services provided by the Construction Manager (CM) in overseeing the construction project on behalf of the Owner. It establishes the contractual and financial obligations of both parties, helping to minimize disputes and ensure a successful delivery of the project. Some key provisions included in a Maryland Agreement between Owner and Construction Manager for Services may include: 1. Project Description: This section identifies the project's location, purpose, and overall objectives. It provides a detailed description of the scope of work, including any specific requirements, permits, or regulations that may be applicable to the project. 2. Roles and Responsibilities: This portion of the agreement clearly defines the roles and responsibilities of the Owner and the Construction Manager. It outlines the specific duties and obligations that each party is expected to fulfill throughout the duration of the construction project. 3. Payment Terms: This section discusses the financial aspects of the agreement, including the CM's compensation structure, payment milestones, and any additional costs for changes or modifications requested by the Owner. It may also highlight the consequences of late payments or non-payment. 4. Project Schedule and Milestones: This section establishes the overall project timeline, including expected start and completion dates, as well as specific milestones or deadlines that need to be met. It provides a framework for the CM to manage the project efficiently and keep it on track. 5. Change Orders: This clause addresses any changes or modifications to the original scope of work and the process for approving and implementing such changes. It ensures that any alterations are properly documented, agreed upon, and appropriately compensated. 6. Dispute Resolution: This section outlines the procedure for resolving any disputes or conflicts that may arise during the course of the construction project. It may include a requirement for mediation, arbitration, or litigation, depending on the preferences of the parties involved. Different types of Maryland Agreements between Owner and Construction Manager for Services may exist depending on various factors such as the size and complexity of the project, the delivery method chosen (e.g., design-bid-build, design-build, construction manager at risk), and the specific needs and preferences of the parties involved. Some specialized agreements may also address unique situations or project requirements, such as Maryland Agreement between Owner and Construction Manager for Services in Federal Government Projects, Maryland Agreement between Owner and Construction Manager for Services in Public Infrastructure Projects, or Maryland Agreement between Owner and Construction Manager for Services in Residential Construction Projects. In conclusion, a Maryland Agreement between Owner and Construction Manager for Services in Overseeing a Construction Project is a crucial legal document that outlines the expectations, responsibilities, and obligations of both the Owner and the Construction Manager. It ensures effective project management, clear communication, and successful project execution.