This form is designed for use between Framing Contractors and Property Owners and may be executed with either a cost plus or fixed fee payment arrangement. This contract addresses such matters as change orders, work site information, warranty and insurance. This form was specifically drafted to comply with the laws of the State of Missouri.
Missouri Framing Contract for Contractor
Category:
State:
Missouri
Control #:
MO-00462-2
Format:
Word;
Rich Text
Instant download
Description
Free preview
How to fill out Missouri Framing Contract For Contractor?
Have any template from 85,000 legal documents including Missouri Framing Contract for Contractor on-line with US Legal Forms. Every template is prepared and updated by state-accredited attorneys.
If you have already a subscription, log in. Once you are on the form’s page, click the Download button and go to My Forms to get access to it.
In case you have not subscribed yet, follow the tips below:
- Check the state-specific requirements for the Missouri Framing Contract for Contractor you need to use.
- Look through description and preview the sample.
- As soon as you are confident the template is what you need, click Buy Now.
- Select a subscription plan that works well for your budget.
- Create a personal account.
- Pay in one of two appropriate ways: by card or via PayPal.
- Pick a format to download the file in; two options are available (PDF or Word).
- Download the file to the My Forms tab.
- After your reusable form is ready, print it out or save it to your device.
With US Legal Forms, you will always have instant access to the right downloadable template. The service gives you access to forms and divides them into categories to streamline your search. Use US Legal Forms to obtain your Missouri Framing Contract for Contractor fast and easy.
Form popularity
FAQ
Name of contractor and contact information. Name of homeowner and contact information. Describe property in legal terms. List attachments to the contract. The cost. Failure of homeowner to obtain financing. Description of the work and the completion date. Right to stop the project.
In Missouri, a mechanics lien must be filed within 6 months after the last day of services or materials were provided. This date is crucial to the rights of the project participant. The lien should be filed with the recorder of deeds in the county where the property is located.
Get it in writing. Keep it simple. Deal with the right person. Identify each party correctly. Spell out all of the details. Specify payment obligations. Agree on circumstances that terminate the contract. Agree on a way to resolve disputes.
Check Contract Basics. The basic job of a contractor agreement is to spell out the scope of the project's work. Set a Payment Schedule. Schedule Start and End Dates. Specify Change Orders. Research Your Arbitration Options. Turn Down the Contractor's Warranty.
Timeframe or key milestones of the project; hours of work; deliverables of the project; and. way the business will pay the contractor for their services.
Scope of Work, Selection Sheet and Drawings. License Number and Insurance. Description of Change Orders. Warranty information. Subcontractor Agreements. Payment schedule. Completion Schedule / Timeline. Clauses Required by Law.
Your general contractor should provide proof of licensing, bonding and insurance before a project starts, but it's better to have it in hand before you sign any contracts. It's important that contractors carry any licensing and/or certification required for the specific trade or skill they practice.
Identifying/Contact Information. Title and Description of the Project. Projected Timeline and Completion Date. Cost Estimate and Payment Schedule. Stop Work Clause and Stop Payment Clause. Act of God Clause. Change Order Agreement. Warranty.
Name of contractor and contact information. Name of homeowner and contact information. Describe property in legal terms. List attachments to the contract. The cost. Failure of homeowner to obtain financing. Description of the work and the completion date. Right to stop the project.