North Dakota Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents

• Category: Construction - Contractors
• State: Multi-State
• Control #: US-13202BG
• Format: Word; Rich Text

Description

This form is a contract for the construction of a building with Contractor agreeing to furnish all materials and to perform all work as required by contracts enumerated in the contract for construction. A North Dakota Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legally binding agreement between a property owner or developer (referred to as the "Owner") and a construction contractor. This contract outlines the specific obligations, responsibilities, and terms that govern the construction project in the state of North Dakota. The contract encompasses various essential elements and provisions that ensure the successful completion of the building project. It details the scope of work, materials to be used, project timeline, budget, and all other necessary specifications necessary for the construction of the building. The North Dakota Contract for Construction of Building is designed to protect both parties involved by establishing clear expectations and providing a firm legal framework. Key elements that may be included in a North Dakota Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents are: 1. Identification of Parties: — Names and contact information for both the Owner/Developer and the Contractor. 2. Scope of Work: — Detailed description of the construction project, including architectural plans, engineering drawings, and any other relevant documents. — Specifications regarding the size, layout, and design of the building. — Specific requirements for materials, finishes, and installations. 3. Project Timeline: — Start and end dates of construction— - Milestones, deadlines, or significant stages. — Provision for change orders, delays, and potential extensions of time. 4. Payment Terms: — Total contract price or agreed-upon sum for the project. — Payment schedule, including down payment, progress payments, and final payment. — Retention amount, if applicable— - Procedure for handling any additional costs or change orders. 5. Insurance and Indemnification: — Insurance requirements for both parties, including liability and workers' compensation coverage. — Responsibility for damages, accidents, or injuries occurring on the construction site. — Indemnification clause to protect each party from claims or losses. 6. Dispute Resolution: — Mechanism for resolving disputes, such as mediation, arbitration, or litigation. — Selection of jurisdiction and venue for legal proceedings. 7. Termination of Contract: — Circumstances under which either party may terminate the contract. — Procedures and potential consequences for termination, including any penalty or damages. Different types of North Dakota Contracts for Construction of Building may exist, depending on the specific nature of the project, parties involved, or industry standards. For instance, contracts may be further categorized based on variations such as residential, commercial, public works, or government-funded projects. Nonetheless, the core elements mentioned above generally remain consistent within the context of North Dakota construction contracts.

A North Dakota Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legally binding agreement between a property owner or developer (referred to as the "Owner") and a construction contractor. This contract outlines the specific obligations, responsibilities, and terms that govern the construction project in the state of North Dakota. The contract encompasses various essential elements and provisions that ensure the successful completion of the building project. It details the scope of work, materials to be used, project timeline, budget, and all other necessary specifications necessary for the construction of the building. The North Dakota Contract for Construction of Building is designed to protect both parties involved by establishing clear expectations and providing a firm legal framework. Key elements that may be included in a North Dakota Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents are: 1. Identification of Parties: — Names and contact information for both the Owner/Developer and the Contractor. 2. Scope of Work: — Detailed description of the construction project, including architectural plans, engineering drawings, and any other relevant documents. — Specifications regarding the size, layout, and design of the building. — Specific requirements for materials, finishes, and installations. 3. Project Timeline: — Start and end dates of construction— - Milestones, deadlines, or significant stages. — Provision for change orders, delays, and potential extensions of time. 4. Payment Terms: — Total contract price or agreed-upon sum for the project. — Payment schedule, including down payment, progress payments, and final payment. — Retention amount, if applicable— - Procedure for handling any additional costs or change orders. 5. Insurance and Indemnification: — Insurance requirements for both parties, including liability and workers' compensation coverage. — Responsibility for damages, accidents, or injuries occurring on the construction site. — Indemnification clause to protect each party from claims or losses. 6. Dispute Resolution: — Mechanism for resolving disputes, such as mediation, arbitration, or litigation. — Selection of jurisdiction and venue for legal proceedings. 7. Termination of Contract: — Circumstances under which either party may terminate the contract. — Procedures and potential consequences for termination, including any penalty or damages. Different types of North Dakota Contracts for Construction of Building may exist, depending on the specific nature of the project, parties involved, or industry standards. For instance, contracts may be further categorized based on variations such as residential, commercial, public works, or government-funded projects. Nonetheless, the core elements mentioned above generally remain consistent within the context of North Dakota construction contracts.