A contract for the employment of an architect, an engineer, or a surveyor should identify the parties clearly, state the relationship between them, and spell out in reasonable detail the services to be performed under the contract. The contract should also clearly specify the rights of the architect, engineer, or surveyor in respect to such things as compensation, ownership and use of plans, working drawings, etc.
This form is a generic example that may be referred to when preparing such a form for your particular state. It is for illustrative purposes only. Local laws should be consulted to determine any specific requirements for such a form in a particular jurisdiction.
Nevada Project Agreement Between a Non-Profit Church Corporation and Architect: A Comprehensive Overview Introduction: A Nevada Project Agreement between a non-profit church corporation and an architect is a legally binding document that outlines the terms and conditions surrounding the architectural services provided by an architect to a non-profit church corporation in Nevada. This agreement helps in establishing a clear understanding, scope, and responsibilities between the two parties involved in a construction project for the church building or facility. Different types of Nevada Project Agreements may include agreements for new construction projects, remodels, renovations, or expansions. Key Clauses and Sections: 1. Parties involved: Clearly identify the non-profit church corporation and the architect as the primary parties to the agreement. Include their legal names and contact information. 2. Project Description: Provide a detailed description of the scope of the project, including the purpose, location, and desired outcome. Specify if it involves new construction, renovation, or expansion. 3. Architectural Services: Outline the specific services to be provided by the architect, such as preparing conceptual designs, schematic designs, construction plans and specifications, obtaining permits, and overseeing construction progress. 4. Project Timeline: Set forth a well-defined timeline or schedule for the project, including key milestones, construction start and completion dates, and specific phases of work. 5. Compensation: Clearly state the compensation arrangement, whether it's a fixed fee, hourly rate, or a percentage of the project cost. Include information on how and when payments will be made, any retainers or deposits required, and procedures for invoicing and payment. 6. Change Orders: Specify the process for change orders and alterations to the scope of work. Include provisions for additional compensation or time extensions, ensuring that all parties agree in writing. 7. Insurance and Liability: Detail the insurance requirements for both parties, including professional liability insurance, general liability insurance, and workers' compensation coverage. Clarify the responsibilities and liabilities of each party related to property damage, injury, or other losses. 8. Dispute Resolution: Outline the procedures for resolving any disagreement or dispute that may arise during the project. This may include mediation, arbitration, or litigation, depending on the preferences of the parties involved. 9. Confidentiality and Intellectual Property: Address the treatment of sensitive information, intellectual property rights, and proprietary designs, ensuring that they are appropriately protected and not disclosed to third parties without prior consent. 10. Termination: Describe the conditions under which the agreement may be terminated by either party, including the required notice period and any associated obligations or liabilities. Conclusion: A Nevada Project Agreement Between a Non-Profit Church Corporation and an Architect is a critical document that ensures proper communication, understanding, and expectations between the non-profit church corporation and the architect throughout the project. By specifying the scope of work, project timeline, compensation terms, and other important details, this agreement forms the foundation for a successful collaboration toward the shared goal of realizing an architecturally sound and functional church facility.
