Wisconsin Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents

• Category: Construction - Contractors
• State: Multi-State
• Control #: US-13202BG
• Format: Word; Rich Text

Description

This form is a contract for the construction of a building with Contractor agreeing to furnish all materials and to perform all work as required by contracts enumerated in the contract for construction. The Wisconsin Contract for Construction of a Building with a Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legal agreement that outlines the terms and conditions between a property owner and a contractor for the construction of a building in the state of Wisconsin. This contract is designed to ensure that all parties involved are clear on their responsibilities, rights, and obligations throughout the construction process, as well as to protect their interests. The Wisconsin Contract for Construction of a Building with a Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents typically includes the following key elements: 1. Parties Involved: This section identifies the parties involved in the contract, including the property owner (referred to as the owner) and the contractor responsible for construction. It may also include information on any subcontractors or other parties involved in the project. 2. Scope of Work and Project Details: This section provides a detailed description of the project, including the scope of work to be performed by the contractor. It may include architectural plans, engineering drawings, specifications, and other contract documents that define the project requirements. 3. Contractor's Responsibilities: This portion outlines the specific duties and responsibilities of the contractor, such as obtaining necessary permits, coordinating with suppliers and subcontractors, adhering to safety regulations, and completing the construction work as specified in the contract documents. 4. Owner's Responsibilities: This section highlights the responsibilities of the property owner, such as providing access to the construction site, ensuring a safe working environment, and timely payment for completed work. 5. Timeframe and Schedule: This part establishes the project's start and end dates, as well as any milestones or deadlines for completion of various stages. It may also address potential penalties or extensions of time for delays caused by either party. 6. Payment Terms: The contract specifies the agreed-upon compensation for the contractor's services, including how and when payments will be made. This may include provisions for progress payments based on completed milestones or a schedule of values. 7. Changes and Extra Work: This section addresses any potential changes or modifications to the project scope, including how they will be communicated, documented, and compensated. It may also cover how claims or disputes regarding changes will be resolved. 8. Insurance and Liability: The contract typically requires the contractor to carry adequate insurance coverage and outlines the respective parties' responsibilities for liability and indemnification. 9. Termination and Dispute Resolution: This section outlines the conditions under which either party may terminate the contract and the process for resolving any disputes that arise during construction. It may include provisions for mediation, arbitration, or litigation. Different types or variations of this contract may exist based on various factors such as the scale of the project, the type of construction (e.g., residential, commercial), and specific industry standards. However, the basics of the Wisconsin Contract for Construction of a Building remain consistent across these variations, ensuring a fair and standardized agreement between the owner and contractor.

The Wisconsin Contract for Construction of a Building with a Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legal agreement that outlines the terms and conditions between a property owner and a contractor for the construction of a building in the state of Wisconsin. This contract is designed to ensure that all parties involved are clear on their responsibilities, rights, and obligations throughout the construction process, as well as to protect their interests. The Wisconsin Contract for Construction of a Building with a Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents typically includes the following key elements: 1. Parties Involved: This section identifies the parties involved in the contract, including the property owner (referred to as the owner) and the contractor responsible for construction. It may also include information on any subcontractors or other parties involved in the project. 2. Scope of Work and Project Details: This section provides a detailed description of the project, including the scope of work to be performed by the contractor. It may include architectural plans, engineering drawings, specifications, and other contract documents that define the project requirements. 3. Contractor's Responsibilities: This portion outlines the specific duties and responsibilities of the contractor, such as obtaining necessary permits, coordinating with suppliers and subcontractors, adhering to safety regulations, and completing the construction work as specified in the contract documents. 4. Owner's Responsibilities: This section highlights the responsibilities of the property owner, such as providing access to the construction site, ensuring a safe working environment, and timely payment for completed work. 5. Timeframe and Schedule: This part establishes the project's start and end dates, as well as any milestones or deadlines for completion of various stages. It may also address potential penalties or extensions of time for delays caused by either party. 6. Payment Terms: The contract specifies the agreed-upon compensation for the contractor's services, including how and when payments will be made. This may include provisions for progress payments based on completed milestones or a schedule of values. 7. Changes and Extra Work: This section addresses any potential changes or modifications to the project scope, including how they will be communicated, documented, and compensated. It may also cover how claims or disputes regarding changes will be resolved. 8. Insurance and Liability: The contract typically requires the contractor to carry adequate insurance coverage and outlines the respective parties' responsibilities for liability and indemnification. 9. Termination and Dispute Resolution: This section outlines the conditions under which either party may terminate the contract and the process for resolving any disputes that arise during construction. It may include provisions for mediation, arbitration, or litigation. Different types or variations of this contract may exist based on various factors such as the scale of the project, the type of construction (e.g., residential, commercial), and specific industry standards. However, the basics of the Wisconsin Contract for Construction of a Building remain consistent across these variations, ensuring a fair and standardized agreement between the owner and contractor.