This form is designed for use between Paving Contractors and Property Owners and may be executed with either a cost plus or fixed fee payment arrangement. This contract addresses such matters as change orders, work site information, warranty and insurance. This form was specifically drafted to comply with the laws of the State of California.
A San Jose California Paving Contract for Contractor is a legal document that outlines the terms and conditions of a paving project between a contractor and their client. This contract ensures that both parties have a clear understanding of the work to be performed, the payment terms, and any other details related to the project. The paving contract typically includes the following elements: 1. Project Details: This section provides an overview of the paving project, including the location, scope of work, and timeline. 2. Terms and Conditions: This section specifies the obligations and responsibilities of both the contractor and the client. It outlines the contractor's duties, such as providing all necessary materials, equipment, and labor, as well as adhering to safety regulations. The client's responsibilities, such as providing access to the worksite and making timely payments, are also outlined here. 3. Work Specifications: This section details the specific tasks and materials required for the project. It may include information on excavation, grading, asphalt or concrete types, thickness, and surface finishes. 4. Pricing and Payment Terms: This section defines how the project will be priced and establishes the payment terms. It may include details on the unit costs for materials, labor rates, and any additional charges or fees. Payment terms, such as the amount and schedule for progress payments, are also specified. 5. Change Orders: This section addresses the possibility of changes or modifications during the course of the project. It outlines the procedures for requesting and approving change orders, including any associated costs or time extensions. 6. Insurance and Liability: This section specifies the insurance coverage required by the contractor, including general liability and worker's compensation insurance. It also clarifies the liability of both parties in case of damages, accidents, or delays. 7. Termination and Dispute Resolution: This section outlines the conditions under which the contract can be terminated by either party, as well as the procedures for dispute resolution, such as mediation or arbitration. There may be different types of San Jose California Paving Contracts for Contractors depending on the specific nature of the project or the preferences of the parties involved. For example, there could be contracts for residential paving projects, commercial projects, or government contracts. The specific contract may differ in terms of project size, complexity, and legal requirements.
