This form is designed for use between Framing Contractors and Property Owners and may be executed with either a cost plus or fixed fee payment arrangement. This contract addresses such matters as change orders, work site information, warranty and insurance. This form was specifically drafted to comply with the laws of the State of Michigan.
The Detroit Michigan Framing Contract for Contractor is a legally binding agreement that outlines the terms and conditions between a contractor and a client in the construction industry specifically related to framing services in the city of Detroit, Michigan. This contract is designed to protect the rights and interests of both parties involved in a framing project, while ensuring the smooth execution of the project and adherence to local regulations. Keywords: 1. Framing Contract: This refers to an agreement specifically focused on the framing aspect of a construction project. It covers details such as the scope of work, payment terms, timelines, and responsibilities of both parties. 2. Contractor: The contractor is the professional or company responsible for providing framing services. They are experienced in building and installing the structural framework of a structure. 3. Detroit, Michigan: This contract is specifically tailored to the construction industry operating within the city of Detroit, Michigan. This helps to ensure compliance with local building codes, permits, and regulations unique to the region. 4. Terms and Conditions: This refers to the stipulations and obligations that both parties must adhere to throughout the contract period. It includes details on payment schedules, project milestones, change orders, warranties, and dispute resolution procedures. 5. Scope of Work: The contract clearly defines the specific tasks and services related to framing that the contractor will be responsible for. This may include assembling structural components, beams, trusses, and installing exterior wall systems. 6. Payment Terms: This outlines the agreed-upon method, frequency, and amounts of payment for the contractor's services. It includes details on deposits, progress payments, and the final payment upon project completion. 7. Timelines: The contract sets clear deadlines and milestones for the completion of the framing work, allowing for effective project management and scheduling. 8. Responsibilities: The document outlines the responsibilities of both the contractor and the client to ensure a smooth execution of the project. This includes providing necessary documents, materials, utilities, and access to the construction site, as well as ensuring compliance with safety regulations. 9. Change Orders: These are alterations or modifications requested by the client during the project that require adjustments to the original contract terms, including additional costs or time extensions. The contract outlines the process for requesting and approving change orders. 10. Warranties: The contract often includes information about the warranties and guarantees that the contractor provides for their work, ensuring that the framing services meet industry standards and will be free from defects. 11. Dispute Resolution: This section of the contract provides a process for resolving any disputes that may arise during the project. It may stipulate the use of mediation, arbitration, or legal action if necessary. Different types of Detroit Michigan Framing Contracts for Contractors may include variations based on the size of the project, the specific type of framing required (such as residential or commercial), and any unique considerations for certain types of structures (such as historical buildings or government properties).
