Fulton Georgia Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents

• Category: Construction - Contractors
• State: Multi-State
• County: Fulton
• Control #: US-13202BG
• Format: Word; Rich Text

Description

This form is a contract for the construction of a building with Contractor agreeing to furnish all materials and to perform all work as required by contracts enumerated in the contract for construction. A Fulton Georgia Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legally binding agreement between a contractor and a client in Fulton County, Georgia. This contract outlines the terms and conditions under which the contractor will provide all necessary materials and perform all construction work as specified in the contract documents. The purpose of this contract is to ensure that the construction project in Fulton, Georgia proceeds smoothly, with clear responsibilities and expectations for both parties involved. It protects the rights and interests of both the contractor and the client and provides a framework for the successful completion of the building project. The key sections of this contract typically include: 1. Parties involved: This section identifies the full legal names and contact information of the contractor (the party responsible for providing materials and performing the construction work) and the client (the party who hires the contractor). 2. Scope of work: This section details the specific work to be performed, including the construction plans, specifications, and any other relevant contract documents. It outlines the size, design, materials, and quality standards expected for the building project. 3. Materials and equipment: This section specifies that the contractor shall furnish all necessary materials, labor, tools, equipment, and services in order to complete the project as described in the contract documents. It may also include provisions for handling and storage of materials on-site. 4. Project timeline: This section sets forth the duration and schedule for the construction project. It may include milestones, completion dates, and penalties for delays or failure to meet deadlines. 5. Payment provisions: This section outlines the agreed-upon payment terms, including the total contract price, payment schedule, and any specific conditions for invoicing and payment methods. 6. Change orders: This section addresses the process for making changes to the original contract, including how changes will be requested, evaluated, and documented. It may also stipulate any additional costs or time extensions resulting from change orders. 7. Warranties and guarantees: This section establishes any warranties or guarantees provided by the contractor, such as workmanship, materials, or specific system performance. It may also include insurance requirements and liability provisions. 8. Dispute resolution and termination: This section describes the procedures for resolving any disputes that may arise during the construction project. It may include mediation, arbitration, or litigation processes. Additionally, it may outline the conditions under which the contract may be terminated by either party. There are no specific variations or different types of Fulton Georgia Contracts for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents. However, the specific terms and conditions within each contract may vary depending on the nature of the construction project, the parties involved, and any unique requirements or regulations in Fulton County, Georgia.

A Fulton Georgia Contract for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents is a legally binding agreement between a contractor and a client in Fulton County, Georgia. This contract outlines the terms and conditions under which the contractor will provide all necessary materials and perform all construction work as specified in the contract documents. The purpose of this contract is to ensure that the construction project in Fulton, Georgia proceeds smoothly, with clear responsibilities and expectations for both parties involved. It protects the rights and interests of both the contractor and the client and provides a framework for the successful completion of the building project. The key sections of this contract typically include: 1. Parties involved: This section identifies the full legal names and contact information of the contractor (the party responsible for providing materials and performing the construction work) and the client (the party who hires the contractor). 2. Scope of work: This section details the specific work to be performed, including the construction plans, specifications, and any other relevant contract documents. It outlines the size, design, materials, and quality standards expected for the building project. 3. Materials and equipment: This section specifies that the contractor shall furnish all necessary materials, labor, tools, equipment, and services in order to complete the project as described in the contract documents. It may also include provisions for handling and storage of materials on-site. 4. Project timeline: This section sets forth the duration and schedule for the construction project. It may include milestones, completion dates, and penalties for delays or failure to meet deadlines. 5. Payment provisions: This section outlines the agreed-upon payment terms, including the total contract price, payment schedule, and any specific conditions for invoicing and payment methods. 6. Change orders: This section addresses the process for making changes to the original contract, including how changes will be requested, evaluated, and documented. It may also stipulate any additional costs or time extensions resulting from change orders. 7. Warranties and guarantees: This section establishes any warranties or guarantees provided by the contractor, such as workmanship, materials, or specific system performance. It may also include insurance requirements and liability provisions. 8. Dispute resolution and termination: This section describes the procedures for resolving any disputes that may arise during the construction project. It may include mediation, arbitration, or litigation processes. Additionally, it may outline the conditions under which the contract may be terminated by either party. There are no specific variations or different types of Fulton Georgia Contracts for Construction of Building with Contractor to Furnish all Materials and Perform all Work as Required by Enumerated Contract Documents. However, the specific terms and conditions within each contract may vary depending on the nature of the construction project, the parties involved, and any unique requirements or regulations in Fulton County, Georgia.