Cook Illinois Standard Form of Agreement for Design Services

• Category: Contracts - Design
• State: Multi-State
• County: Cook
• Control #: US-1340779BG
• Format: Word

Description

Design Services means the complete architectural design and engineering for the Trade Contractor Work, and includes all labor, materials, equipment and services to be provided by the Trade Contractor to fulfill its obligations under the Trade Contract Agreement. Cook Illinois Standard Form of Agreement for Design Services is a legally binding document that outlines the terms and conditions between Cook Illinois Corporation, a transportation company based in Illinois, and design service providers. This agreement is specifically tailored for design professionals who are engaged in providing services related to the planning, design, and implementation of various projects undertaken by Cook Illinois. This standard form agreement covers a wide range of design services, including architectural, engineering, interior design, landscape architecture, and other related disciplines. It is created to ensure clarity, mitigate risks, and establish a fair working relationship between Cook Illinois and the design service providers. The Cook Illinois Standard Form of Agreement for Design Services includes several essential sections: 1. Introduction and Scope: This section outlines the purpose and scope of the agreement, specifying the parties involved, project details, and the services to be provided by the design professionals. 2. Compensation: The agreement clearly defines the compensation structure, payment terms, and any additional expenses related to the provision of design services. It may also include provisions for invoicing, milestones, and reimbursable costs. 3. Design Services: This section outlines the specific design services to be rendered by the design professionals, which may include conceptual design, technical drawings, project management, and coordination with other contractors or parties involved. 4. Copyright and Intellectual Property Rights: The agreement addresses ownership and usage rights of design documents, drawings, and other intellectual property created during the project. It may specify whether Cook Illinois receives exclusive rights or licenses to use the deliverables. 5. Schedule and Deliverables: This section defines the expected timeline for project completion and submission of deliverables. It may include milestones, deadlines, and any penalties for late delivery. 6. Changes and Modifications: This clause addresses the procedure for making changes, revisions, or modifications to the original scope of work. It includes provisions for additional compensation or time extensions resulting from such changes. 7. Termination: This section outlines the conditions and procedures for terminating the agreement, including grounds for termination, notice periods, and any applicable termination fees. 8. Dispute Resolution: If any disputes arise during the project, this section outlines the process for resolving conflicts, which may involve mediation, arbitration, or litigation. It's important to note that different types of Cook Illinois Standard Forms of Agreement for Design Services may exist, tailored to specific project types or design disciplines. These variations may address industry-specific requirements, such as transportation infrastructure design, building systems design, or specialized services like acoustics or sustainable design. Each form usually has slight variations in language and provisions to cater to the unique needs of the specific projects or design services.

Cook Illinois Standard Form of Agreement for Design Services is a legally binding document that outlines the terms and conditions between Cook Illinois Corporation, a transportation company based in Illinois, and design service providers. This agreement is specifically tailored for design professionals who are engaged in providing services related to the planning, design, and implementation of various projects undertaken by Cook Illinois. This standard form agreement covers a wide range of design services, including architectural, engineering, interior design, landscape architecture, and other related disciplines. It is created to ensure clarity, mitigate risks, and establish a fair working relationship between Cook Illinois and the design service providers. The Cook Illinois Standard Form of Agreement for Design Services includes several essential sections: 1. Introduction and Scope: This section outlines the purpose and scope of the agreement, specifying the parties involved, project details, and the services to be provided by the design professionals. 2. Compensation: The agreement clearly defines the compensation structure, payment terms, and any additional expenses related to the provision of design services. It may also include provisions for invoicing, milestones, and reimbursable costs. 3. Design Services: This section outlines the specific design services to be rendered by the design professionals, which may include conceptual design, technical drawings, project management, and coordination with other contractors or parties involved. 4. Copyright and Intellectual Property Rights: The agreement addresses ownership and usage rights of design documents, drawings, and other intellectual property created during the project. It may specify whether Cook Illinois receives exclusive rights or licenses to use the deliverables. 5. Schedule and Deliverables: This section defines the expected timeline for project completion and submission of deliverables. It may include milestones, deadlines, and any penalties for late delivery. 6. Changes and Modifications: This clause addresses the procedure for making changes, revisions, or modifications to the original scope of work. It includes provisions for additional compensation or time extensions resulting from such changes. 7. Termination: This section outlines the conditions and procedures for terminating the agreement, including grounds for termination, notice periods, and any applicable termination fees. 8. Dispute Resolution: If any disputes arise during the project, this section outlines the process for resolving conflicts, which may involve mediation, arbitration, or litigation. It's important to note that different types of Cook Illinois Standard Forms of Agreement for Design Services may exist, tailored to specific project types or design disciplines. These variations may address industry-specific requirements, such as transportation infrastructure design, building systems design, or specialized services like acoustics or sustainable design. Each form usually has slight variations in language and provisions to cater to the unique needs of the specific projects or design services.